Loading...
Sunbeam Consulting Inc - FY2018-015 CITY OF RANCHO PALOS VERDES CONTRACT SERVICES AGREEMENT FOR INSPECTION SERVICES THIS PROFESSIONAL SERVICES AGREEMENT (herein "Agreement") is made and entered into this 15th day of May, 2018, by and between the CITY OF RANCHO PALOS VERDES, a general law city& municipal corporation ("City") and Sunbeam, Consulting, Inc., a California corporation d/b/a Sunbeam Consulting(herein"Consultant"). NOW, THEREFORE,the parties hereto agree as follows: 1. SERVICES OF CONSULTANT 1.1 Scope of Services. In compliance with all of the terms and conditions of this Agreement, the Consultant shall perform the work or services set forth in the "Scope of Services" attached hereto as Exhibit "A" and incorporated herein by reference. Consultant warrants that it has the experience and ability to perform all work and services required hereunder and that it shall diligently perform such work and services in a professional and satisfactory manner. 1.2 Compliance With Law. All work and services rendered hereunder shall be provided in accordance with all ordinances, resolutions, statutes, rules, and regulations of the City and any Federal, State or local governmental agency of competent jurisdiction. 1.3 California Labor Law. If the Scope of Services includes any "public work" or"maintenance work," as those terms are defined in California Labor Code section 1720 et seq. and California Code of Regulations, Title 8, Section 16000 et seq., and if the total compensation is $1,000 or more, Consultant shall pay prevailing wages for such work and comply with the requirements in California Labor Code section 1770 et seq. and 1810 et seq., and all other applicable laws, including the following requirements: (a) Public Work. The Parties acknowledge that some or all of the work to be performed under this Agreement is a "public work" as defined in Labor Code Section 1720 and that this Agreement is therefore subject to the requirements of Division 2, Part 7, Chapter 1 (commencing with Section 1720) of the California Labor Code relating to public works contracts and the rules and regulations established by the Depaitment of Industrial Relations ("DIR") implementing such statutes. The work performed under this Agreement is subject to compliance monitoring and enforcement by the DIR. Contractor shall post job site notices, as prescribed by regulation. (b) Prevailing Wages. Contractor shall pay prevailing wages to the extent required by Labor Code Section 1771. Pursuant to Labor Code Section 1773.2, copies of the prevailing rate of per diem wages are on file at City Hall and will be made available to any interested party on request. By initiating any work under this Agreement, Contractor acknowledges receipt of a copy of the Department of Industrial Relations (DIR) determination of the prevailing rate of per diem wages, and Contractor shall post a copy of the same at each job site where work is performed under this Agreement. 01203.0006/471643.4 1 (c) Penalty for Failure to Pay Prevailing Wages. Contractor shall comply with and be bound by the provisions of Labor Code Sections 1774 and 1775 concerning the payment of prevailing rates of wages to workers and the penalties for failure to pay prevailing wages. The Contractor shall, as a penalty to the City, forfeit two hundred dollars ($200) for each calendar day, or portion thereof, for each worker paid less than the prevailing rates as determined by the DER for the work or craft in which the worker is employed for any public work done pursuant to this Agreement by Contractor or by any subcontractor. (d) Payroll Records. Contractor shall comply with and be bound by the provisions of Labor Code Section 1776, which requires Contractor and each subcontractor to: keep accurate payroll records and verify such records in writing under penalty of perjury, as specified in Section 1776; certify and make such payroll records available for inspection as provided by Section 1776; and inform the City of the location of the records. (e) Apprentices. Contractor shall comply with and be bound by the provisions of Labor Code Sections 1777.5, 1777.6, and 1777.7 and California Code of Regulations Title 8, Section 200 et seq. concerning the employment of apprentices on public works projects. Contractor shall be responsible for compliance with these aforementioned Sections for all apprenticeable occupations. Prior to commencing work under this Agreement, Contractor shall provide City with a copy of the infolmation submitted to any applicable apprenticeship program. Within sixty(60) days after concluding work pursuant to this Agreement, Contractor and each of its subcontractors shall submit to the City a verified statement of the journeyman and apprentice hours performed under this Agreement. Eight-Hour Work Day. Contractor acknowledges that eight (8)hours labor constitutes a legal day's work. Contractor shall comply with and be bound by Labor Code Section 1810. (g) Penalties for Excess Hours. Contractor shall comply with and be bound by the provisions of Labor Code Section 1813 concerning penalties for workers who work excess hours. The Contractor shall, as a penalty to the City, forfeit twenty-five dollars ($25) for each worker employed in the performance of this Agreement by the Contractor or by any subcontractor for each calendar day during which such worker is required or permitted to work more than eight (8) hours in any one calendar day and forty (40) hours in any one calendar week in violation of the provisions of Division 2, Part 7, Chapter 1, Article 3 of the Labor Code. Pursuant to Labor Code section 1815, work performed by employees of Contractor in excess of eight(8) hours per day, and forty (40) hours during any one week shall be permitted upon public work upon compensation for all hours worked in excess of 8 hours per day at not less than one and one-half(11/2) times the basic rate of pay. (h) Workers' Compensation. California Labor Code Sections 1860 and 3700 provide that every employer will be required to secure the payment of compensation to its employees if it has employees. In accordance with the provisions of California Labor Code Section 1861, Contractor certifies as follows: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to 2 01203.0006/471643.4 undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract." Contractor's Authorized Initials (i) Contractor's Responsibility for Subcontractors. For every subcontractor who will perform work under this Agreement, Contractor shall be responsible for such subcontractor's compliance with Division 2, Part 7, Chapter 1 (commencing with Section 1720) of the California Labor Code, and shall make such compliance a requirement in any contract with any subcontractor for work under this Agreement. Contractor shall be required to take all actions necessary to enforce such contractual provisions and ensure subcontractor's compliance, including without limitation, conducting a review of the certified payroll records of the subcontractor on a periodic basis or upon becoming aware of the failure of the subcontractor to pay his or her workers the specified prevailing rate of wages. Contractor shall diligently take corrective action to halt or rectify any such failure by any subcontractor. 1.4 Licenses, Permits, Fees and Assessments. Consultant shall obtain at its sole cost and expense such licenses, peg,nits, and approvals as may be required by law for the performance of the services required by the Agreement. 1.5 Special Requirements. Additional terms and conditions of this Agreement, if any, which are made a part hereof are set forth in the "Special Requirements" attached hereto as Exhibit "B" and incorporated herein by this reference. In the event of a conflict between the provisions of Exhibit "B" and any other provisions of this Agreement, the provisions of Exhibit"B"shall govern. 2. COMPENSATION 2.1 Contract Sum. For the services rendered pursuant to this Agreement, Consultant shall be compensated in accordance with the "Schedule of Compensation" attached hereto as Exhibit "C" and incorporated herein by this reference, but not exceeding the maximum contract amount of Eighteen Thousand Three Hundred Dollars ($18,300.00) ("Contract Sum"). 2.2 Invoices. Each month Consultant shall furnish to City an original invoice for all work performed and expenses incurred during the preceding month in a form approved by City's Director of Finance. By submitting an invoice for payment under this Agreement, Consultant is certifying compliance with all provisions of the Agreement. The invoice shall detail charges for all necessary and actual expenses by the following categories: labor (by sub- category), travel, materials, equipment, supplies, and sub-contractor contracts. Sub-contractor charges shall also be detailed by such categories. Consultant shall not invoice City for any duplicate services perfoinied by more than one person. City shall independently review each invoice submitted by the Consultant to determine whether the work performed and expenses incurred are in compliance with the provisions of this Agreement. Except as to any charges for work performed or expenses incurred by Consultant which are disputed by City, City will use its best efforts to cause Consultant to be paid within 3 01203.0006/471643.4 forty five (45) days of receipt of Consultant's correct and undisputed invoice; however, Consultant acknowledges and agrees that due to City warrant run procedures, the City cannot guarantee that payment will occur within this time period. hi the event any charges or expenses are disputed by City, the original invoice shall be returned by City to Consultant for correction and resubmission. Review and payment by the City of any invoice provided by the Consultant shall not constitute a waiver of any rights or remedies provided herein or any applicable law. 2.3 Additional Services. City shall have the right at any time during the performance of the services, without invalidating this Agreement, to order extra work beyond that specified in the Scope of Services or make changes by altering, adding to or deducting from said work. No such extra work may be undertaken unless a written order is first given by the Contract Officer to the Consultant, incorporating therein any adjustment in (i) the Contract Sum for the actual cost of the extra work, and/or (ii) the time to perform this Agreement, which said adjustments are subject to the written approval of the Consultant. Any increase in compensation of up to ten percent (10%) of the Contract Sum but not exceeding a total contract amount of Five Thousand Dollars ($5,000) or in the time to perform of up to ninety (90) days may be approved by the Contract Officer. Any greater increases, taken either separately or cumulatively, must be approved by the City Council. No claim for an increase in the Contract Sum or time for performance shall be valid unless the procedures established in this Section are followed. 3. PERFORMANCE SCHEDULE 3.1 Time of Essence. Time is of the essence in the performance of this Agreement. 3.2 Schedule of Performance. Consultant shall commence the services pursuant to this Agreement upon receipt of a written notice to proceed and shall perform all services within the time period(s) established in the "Schedule of Performance" attached hereto as Exhibit "D" and incorporated herein by this reference. When requested by the Consultant, extensions to the time period(s) specified in the Schedule of Performance may be approved in writing by the Contract Officer but not exceeding thirty(30) days cumulatively. 3.3 Force Majeure. The time period(s) specified in the Schedule of Performance for performance of the services rendered pursuant to this Agreement shall be extended because of any delays due to unforeseeable causes beyond the control and without the fault or negligence of the Consultant, including,but not restricted to, acts of God or of the public enemy, unusually severe weather, fires, earthquakes, floods, epidemics, quarantine restrictions, riots, strikes, freight embargoes, wars, litigation, and/or acts of any governmental agency, including the City, if the Consultant shall within ten (10) days of the commencement of such delay notify the Contract Officer in writing of the causes of the delay. The Contract Officer shall ascertain the facts and the extent of delay, and extend the time for performing the services for the period of the enforced delay when and if in the judgment of the Contract Officer such delay is justified. The Contract Officer's determination shall be final and conclusive upon the parties to this Agreement. In no event shall Consultant be entitled to recover damages against the City for any delay in the performance of this Agreement, however caused, Consultant's sole remedy being extension of the Agreement pursuant to this Section. 4 01203.0006/471643.4 3.4 Term. Unless earlier terminated in accordance with Article 7 of this Agreement, this Agreement shall continue in full force and effect until completion of the services but not exceeding one (1) year from the date hereof, except as otherwise provided in the Schedule of Performance (Exhibit"D"). 4. COORDINATION OF WORK 4.1 Representative of Consultant. Jim Pugh is hereby designated as being the representative of Consultant authorized to act on its behalf with respect to the work and services specified herein and make all decisions in connection therewith. All personnel of Consultant and any authorized agents shall be under the exclusive direction of the representative of Consultant. Consultant shall utilize only competent personnel to perform services pursuant to this Agreement. Consultant shall make every reasonable effort to maintain the stability and continuity of Consultant's staff and subcontractors, and shall keep City informed of any changes. 4.2 Contract Officer. Ron Dragoo, Principal/City Engineer is hereby designated as being the representative the City authorized to act in its behalf with respect to the work and services specified herein and to make all decisions in connection therewith ("Contract Officer"). 4.3 Prohibition Against Subcontracting or Assignment. Consultant shall not contract with any entity to perform in whole or in part the work or services required hereunder without the express written approval of the City. Neither this Agreement nor any interest herein may be assigned or transferred, voluntarily or by operation of law, without the prior written approval of City. Any such prohibited assignment or transfer shall be void. 4.4 Independent Consultant. Neither the City nor any of its employees shall have any control over the manner, mode or means by which Consultant, its agents or employees, perform the services required herein, except as otherwise set forth. Consultant shall perform all services required herein as an independent contractor of City with only such obligations as are consistent with that role. Consultant shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City, or that it is a member of a joint enterprise with City. 5. INSURANCE AND INDEMNIFICATION 5.1 Insurance Coverages. Without limiting Consultant's indemnification of City, and prior to commencement of any services under this Agreement, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. (a) General liability insurance. Consultant shall maintain commercial general liability insurance with coverage at least as broad as Insurance Services Office form CG 00 01, in an amount not less than $1,000,000 per occurrence, $2,000,000 general aggregate, for bodily injury, personal injury, and property damage. The policy must include contractual liability that has not been amended. Any endorsement restricting standard ISO "insured contract" language will not be accepted. 5 01203.0006/471643.4 (b) Automobile liability insurance. Consultant shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of the Consultant arising out of or in connection with Services to be performed under this Agreement, including coverage for any owned, hired, non- owned or rented vehicles, in an amount not less than $1,000,000 combined single limit for each accident. (c) Professional liability (errors & omissions) insurance. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of$1,000,000 per claim and in the aggregate. Any policy inception date, continuity date, or retroactive date must be before the effective date of this Agreement and Consultant agrees to maintain continuous coverage through a period no less than three (3) years after completion of the services required by this Agreement. (d) Workers' compensation insurance. Consultant shall maintain Workers' Compensation Insurance (Statutory Limits) and Employer's Liability Insurance (with limits of at least$1,000,000). (e) Subcontractors. Consultant shall include all subcontractors as insureds under its policies or shall furnish separate certificates and certified endorsements for each subcontractor. All coverages for subcontractors shall include all of the requirements stated herein. (f) Additional Insurance. Policies of such other insurance, as may be required in the Special Requirements in Exhibit"B". 5.2 General Insurance Requirements. (a) Proof of insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation. Insurance certificates and endorsements must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at any time. (b) Duration of coverage. Consultant shall procure and maintain for the duration of this Agreement insurance against claims for injuries to persons or damages to property, which may arise from or in connection with the performance of the Services hereunder by Consultant, its agents,representatives, employees or subconsultants. (c) Primary/noncontributing. Coverage provided by Consultant shall be primary and any insurance or self-insurance procured or maintained by City shall not be required to contribute with it. The limits of insurance required herein may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non- contributory basis for the benefit of City before the City's own insurance or self-insurance shall be called upon to protect it as a named insured. 6 01203.0006/471643.4 (d) City's rights of enforcement. In the event any policy of insurance required under this Agreement does not comply with these specifications or is canceled and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement. (e) Acceptable insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance or that is on the List of Approved Surplus Line Insurers in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VI (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. (f) Waiver of subrogation. All insurance coverage maintained or procured pursuant to this agreement shall be endorsed to waive subrogation against City, its elected or appointed officers, agents, officials, employees and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants. (g) Enforcement of contract provisions (non-estoppel). Consultant acknowledges and agrees that any actual or alleged failure on the part of the City to inform Consultant of non-compliance with any requirement imposes no additional obligations on the City nor does it waive any rights hereunder. (h) Requirements not limiting. Requirements of specific coverage features or limits contained in this section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Consultant maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for the higher limits maintained by the Consultant. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. (i) Notice of cancellation. Consultant agrees to oblige its insurance agent or broker and insurers to provide to City with a thirty (30) day notice of cancellation (except for nonpayment for which a ten (10) day notice is required) or nonrenewal of coverage for each required coverage. 0) Additional insured status. General liability policies shall provide or be endorsed to provide that City and its officers, officials, employees, and agents, and volunteers shall be additional insureds under such policies. This provision shall also apply to any excess/umbrella liability policies. 7 01203.0006/471643.4 (k) Prohibition of undisclosed coverage limitations. None of the coverages required herein will be in compliance with these requirements if they include any limiting endorsement of any kind that has not been first submitted to City and approved of in writing. (1) Separation of insureds. A severability of interests provision must apply for all additional insureds ensuring that Consultant's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the insurer's limits of liability. The policy(ies) shall not contain any cross-liability exclusions. (m) Pass through clause. Consultant agrees to ensure that its subconsultants, subcontractors, and any other party involved with the project who is brought onto or involved in the project by Consultant, provide the same minimum insurance coverage and endorsements required of Consultant. Consultant agrees to monitor and review all such coverage and assumes all responsibility for ensuring that such coverage is provided in conformity with the requirements of this section. Consultant agrees that upon request, all agreements with consultants, subcontractors, and others engaged in the project will be submitted to City for review. (n) Agency's right to revise specifications. The City reserves the right at any time during the term of the contract to change the amounts and types of insurance required by giving the Consultant ninety (90) days advance written notice of such change. If such change results in substantial additional cost to the Consultant, the City and Consultant may renegotiate Consultant's compensation. (o) Self-insured retentions. Any self-insured retentions must be declared to and approved by City. City reserves the right to require that self-insured retentions be eliminated, lowered, or replaced by a deductible. Self-insurance will not be considered to comply with these specifications unless approved by City. (p) Timely notice of claims. Consultant shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Consultant's performance under this Agreement, and that involve or may involve coverage under any of the required liability policies. (q) Additional insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the work. 5.3 Indemnification. To the full extent permitted by law, Consultant agrees to indemnify, defend and hold harmless the City, its officers, employees and agents ("Indemnified Parties") against, and will hold and save them and each of them harmless from, any and all actions, either judicial, administrative, arbitration or regulatory claims, damages to persons or property, losses, costs, penalties, obligations, errors, omissions or liabilities whether actual or threatened (herein "claims or liabilities") that may be asserted or claimed by any person, firm or entity arising out of or in connection with the negligent performance of the work, operations or activities provided herein of Consultant, its officers, employees, agents, subcontractors, invitees, or any individual or entity for which Consultant is legally liable ("indemnitors"), or arising from Consultant's or indemnitors' reckless or willful misconduct, or arising from Consultant's or 8 01203.0006/471643.4 indemnitors' negligent performance of or failure to perform any term, provision, covenant or condition of this Agreement, except claims or liabilities occurring as a result of City's sole negligence or willful acts or omissions. The indemnity obligation shall be binding on successors and assigns of Consultant and shall survive termination of this Agreement. 6. RECORDS, REPORTS,AND RELEASE OF INFORMATION 6.1 Records. Consultant shall keep, and require subcontractors to keep, such ledgers, books of accounts, invoices, vouchers, canceled checks, reports, studies or other documents relating to the disbursements charged to City and services performed hereunder (the "books and records"), as shall be necessary to perform the services required by this Agreement and enable the Contract Officer to evaluate the performance of such services and shall keep such records for a period of three years following completion of the services hereunder. The Contract Officer shall have full and free access to such books and records at all times during normal business hours of City, including the right to inspect, copy, audit and make records and transcripts from such records. 6.2 Reports. Consultant shall periodically prepare and submit to the Contract Officer such reports concerning the performance of the services required by this Agreement or as the Contract Officer shall require. 6.3 Confidentiality and Release of Information. (a) All information gained or work product produced by Consultant in performance of this Agreement shall be considered confidential, unless such information is in the public domain or already known to Consultant. Consultant shall not release or disclose any such information or work product to persons or entities other than the City without prior written authorization from the Contract Officer. (b) Consultant shall not, without prior written authorization from the Contract Officer or unless requested by the City Attorney, voluntarily provide documents, declarations, letters of support, testimony at depositions, response to interrogatories or other information concerning the work performed under this Agreement. Response to a subpoena or court order shall not be considered"voluntary"provided Consultant gives the City notice of such court order or subpoena. (c) If Consultant provides any information or work product in violation of this Agreement, then the City shall have the right to reimbursement and indemnity from Consultant for any damages, costs and fees, including attorney's fees, caused by or incurred as a result of Consultant's conduct. (d) Consultant shall promptly notify the City should Consultant be served with any summons, complaint, subpoena, notice of deposition, request for documents, interrogatories, request for admissions or other discovery request, court order or subpoena from any party regarding this Agreement and the work performed thereunder. The City retains the right, but has no obligation, to represent Consultant or be present at any deposition, hearing or similar proceeding. Consultant agrees to cooperate fully with the City and to provide the City with the opportunity to review any response to discovery requests provided by Consultant. 9 01203.0006/471643.4 6.4 Ownership of Documents. All studies, surveys, data, notes, computer files, reports, records, drawings, specifications, maps, designs, photographs, documents and other materials (the "documents and materials") prepared by Consultant in the performance of this Agreement shall be the property of the City and shall be delivered to the City upon request of the Contract Officer or upon the termination of this Agreement, and Consultant shall have no claim for further employment or additional compensation as a result of the exercise by the City of its full rights of ownership use, reuse, or assignment of the documents and materials hereunder. Moreover, Consultant with respect to any documents and materials that may qualify as "works made for hire" as defined in 17 U.S.C. § 101, such documents and materials are hereby deemed "works made for hire" for the City. 7. ENFORCEMENT OF AGREEMENT AND TERMINATION 7.1 California Law. This Agreement shall be interpreted, construed and governed both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Los Angeles, State of California. In the event of litigation in a U.S. District Court, venue shall lie exclusively in the Central District of California, in the County of Los Angeles, State of California. 7.2 Disputes; Default. In the event that Consultant is in default under the terms of this Agreement, the City shall not have any obligation or duty to continue compensating Consultant for any work performed after the date of default. Instead, the City may give notice to Consultant of the default and the reasons for the default. The notice shall include the timeframe in which Consultant may cure the default. This timeframe is presumptively thirty (30) days, but may be extended, if circumstances warrant. During the period of time that Consultant is in default, the City shall hold all invoices and shall, when the default is cured, proceed with payment on the invoices. If Consultant does not cure the default, the City may take necessary steps to terminate this Agreement under this Article. 7.3 Legal Action. In addition to any other rights or remedies, either party may take legal action, in law or in equity, to cure, correct or remedy any default, to recover damages for any default, to compel specific performance of this Agreement, to obtain declaratory or injunctive relief, or to obtain any other remedy consistent with the purposes of this Agreement. Notwithstanding any contrary provision herein, Consultant shall file a statutory claim pursuant to Government Code Sections 905 et. seq. and 910 et. seq., in order to pursue any legal action under this Agreement. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative and the exercise by either party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party. 7.4 Liquidated Damages. Since the determination of actual damages for any delay in performance of this Agreement would be extremely difficult or impractical to determine in the event of a breach of this Agreement, the Contractor and its sureties shall be liable for and 10 01203.0006/471643.4 shall pay to the City the sum of Two Hundred Fifty Dollars ($250.00) as liquidated damages for each working day of delay in the performance of any service required hereunder. The City may withhold from any monies payable on account of services performed by the Contractor any accrued liquidated damages. 7.5 Termination Prior to Expiration of Term. This Section shall govern any termination of this Contract except as specifically provided in the following Section for termination for cause. The City reserves the right to terminate this Contract at any time, with or without cause, upon thirty (30) days' written notice to Consultant, except that where termination is due to the fault of the Consultant, the period of notice may be such shorter time as may be determined by the Contract Officer. In addition, the Consultant reserves the right to terminate this Contract at any time, with or without cause, upon sixty (60) days' written notice to City, except that where termination is due to the fault of the City, the period of notice may be such shorter time as the Consultant may determine. Upon receipt of any notice of termination, Consultant shall immediately cease all services hereunder except such as may be specifically approved by the Contract Officer. Except where the Consultant has initiated termination, the Consultant shall be entitled to compensation for all services rendered prior to the effective date of the notice of termination and for any services authorized by the Contract Officer thereafter in accordance with the Schedule of Compensation or such as may be approved by the Contract Officer. In the event the Consultant has initiated termination, the Consultant shall be entitled to compensation only for the reasonable value of the work product actually produced hereunder,but not exceeding the compensation provided therefore in the Schedule of Compensation Exhibit "C". In the event of termination without cause pursuant to this Section, the terminating party need not provide the non-terminating party with the opportunity to cure pursuant to Section 7.2. 7.6 Termination for Default of Consultant. If termination is due to the failure of the Consultant to fulfill its obligations under this Agreement, City may, after compliance with the provisions of Section 7.2, take over the work and prosecute the same to completion by contract or otherwise, and the Consultant shall be liable to the extent that the total cost for completion of the services required hereunder exceeds the compensation herein stipulated(provided that the City shall use reasonable efforts to mitigate such damages), and City may withhold any payments to the Consultant for the purpose of set-off or partial payment of the amounts owed the City as previously stated. 8. MISCELLANEOUS 8.1 Covenant Against Discrimination. Consultant covenants that, by and for itself, its heirs, executors, assigns and all persons claiming under or through them, that there shall be no discrimination against or segregation of, any person or group of persons on account of race, color, creed, religion, sex, gender, sexual orientation, marital status, national origin, ancestry, or other protected class in the performance of this Agreement. Consultant shall take affirmative action to ensure that applicants are employed and that employees are treated during employment without regard to their race, color, creed, religion, sex, gender, sexual orientation, marital status, national origin, ancestry, or other protected class 8.2 Non-liability of City Officers and Employees. No officer or employee of the City shall be personally liable to the Consultant, or any successor in interest, in the event of 11 01203.0006/471643.4 any default or breach by the City or for any amount, which may become due to the Consultant or to its successor, or for breach of any obligation of the terms of this Agreement. 8.3 Notice. Any notice, demand, request, document, consent, approval, or communication either party desires or is required to give to the other party or any other person shall be in writing and either served personally or sent by prepaid, first-class mail, in the case of the City, to the City Manager and to the attention of the Contract Officer (with her/his name and City title), City of Rancho Palos Verdes, 30940 Hawthorne Blvd., California 90275 and in the case of the Consultant, to the person(s) at the address designated on the execution page of this Agreement. Either party may change its address by notifying the other party of the change of address in writing. Notice shall be deemed communicated at the time personally delivered or in seventy-two (72)hours from the time of mailing if mailed as provided in this Section. 8.4 Integration; Amendment. It is understood that there are no oral agreements between the parties hereto affecting this Agreement and this Agreement supersedes and cancels any and all previous negotiations, arrangements, agreements and understandings, if any, between the parties, and none shall be used to interpret this Agreement. This Agreement may be amended at any time by the mutual consent of the parties by an instrument in writing. 8.5 Severability. In the event that part of this Agreement shall be declared invalid or unenforceable by a valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining portions of this Agreement which are hereby declared as severable and shall be interpreted to carry out the intent of the parties hereunder unless the invalid provision is so material that its invalidity deprives either party of the basic benefit of their bargain or renders this Agreement meaningless. 8.6 Waiver. No delay or omission in the exercise of any right or remedy by non-defaulting party on any default shall impair such right or remedy or be construed as a waiver. A party's consent to or approval of any act by the other party requiring the party's consent or approval shall not be deemed to waive or render unnecessary the other party's consent to or approval of any subsequent act. Any waiver by either party of any default must be in writing and shall not be a waiver of any other default concerning the same or any other provision of this Agreement. 8.7 Attorneys' Fees. If either party to this Agreement is required to initiate or defend or made a party to any action or proceeding in any way connected with this Agreement, the prevailing party in such action or proceeding, in addition to any other relief which any be granted, whether legal or equitable, shall be entitled to reasonable attorney's fees, whether or not the matter proceeds to judgment. 8.8 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of this Agreement or any other rule of construction which might otherwise apply. 8.9 Counterparts. 12 01203.0006/471643.4 This Agreement may be executed in counterparts, each of which shall be deemed to be an original, and such counterparts shall constitute one and the same instrument. 8.10 Warranty & Representation of Non-Collusion. No official, officer, or employee of City has any financial interest, direct or indirect, in this Agreement, nor shall any official, officer, or employee of City participate in any decision relating to this Agreement which may affect his/her financial interest or the financial interest of any corporation, partnership, or association in which (s)he is directlyor indirectly interested, or in violation of any corporation, partnership, or association in which (s)he is directly or indirectly interested, or in violation of any State or municipal statute or regulation. The determination of "financial interest" shall be consistent with State law and shall not include interests found to be "remote" or "noninterests" pursuant to Government Code Sections 1091 or 1091.5. Consultant warrants and represents that it has not paid or given, and will not pay or give, to any third party including, but not limited to, any City official, officer, or employee, any money, consideration, or other thing of value as a result or consequence of obtaining or being awarded any agreement. Consultant further warrants and represents that (s)he/it has not engaged in any act(s), omission(s), or other conduct or collusion that would result in the payment of any money, consideration, or other thing of value to any third party including, but not limited to, any City official, officer, or employee, as a result of consequence of obtaining or being awarded any agreement. Consultant is aware of and understands that any such act(s), omission(s) or other conduct resulting in such payment of money, consideration, or other thing of value will render this Agreement void and of no force or effect. Consultant's Authorized Initials 8.11 Corporate Authority. The persons executing this Agreement on behalf of the parties hereto warrant that (i) such party is duly organized and existing, (ii) they are duly authorized to execute and deliver this Agreement on behalf of said party, (iii) by so executing this Agreement, such party is formally bound to the provisions of this Agreement, and (iv) the entering into this Agreement does not violate any provision of any other Agreement to which said party is bound. This Agreement shall be binding upon the heirs, executors, administrators, successors and assigns of the parties. [Signatures On The Following Page] 13 01203.0006/471643.4 IN WITNESS WHEREOF,the parties hereto have executed this Agreement on the date and year first-above written. CITY: CITY OF RANCHO PALOS VERDES, a municipal corpo.ation Doug Willmore, City ManagerA IOW'. .041,1 E 'ily Co ME, City Clerk APPROVED AS TO FORM: ALESHIRE &WYNDER, LLP • Wil lam W. Wyn , City Attorney CONSULTANT: Sunbeam Consulting, Inc., a California corporate 7 By: aoo-. Name: Alan Braatvedt Title. ' dent By: e: Chuck Stephgnn itle: Secretary Address: 1817 Josie Avenue Long Beach, CA 90815 Two corporate officer signatures required when Consultant is a corporation, with one signature required from each of the following groups: 1) Chairman of the Board, President or any Vice President; and 2) Secretary, any Assistant Secretary, Chief Financial Officer or any Assistant Treasurer. CONSULTANT'S SIGNATURES SHALL BE DULY NOTARIZED, AND APPROPRIATE ATTESTATIONS SHALL BE INCLUDED AS MAY BE REQUIRED BY THE BYLAWS, ARTICLES OF INCORPORATION, OR OTHER RULES OR REGULATIONS APPLICABLE TO CONSULTANT'S BUSINESS ENTITY. 14 01203.0006/471643.4 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy or validity of that document. STATE OF CALIFORNIA COUNTY OF L;- -. :r.- • On , 2018 befo -- : ''' # personal ty appearedL...A.,,te/11 er ..10 i -. . ed to me on the/ 2.i/ asi of satisfactory evidenc, o be the person(V) whose names(s) is/axe subscribed to th-'within instrument and acknowledged to me that he/she/they executed the same in hisAaer4lEkoic authorized capacityeiest and that by his/10)&446r signature(s) on the instrument the person(' ), or the entity upon behalf of which the person( acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. ,1- ,,...4, EUZASETH IBARRA WITNESS my f: d and official seal. -'1' -„' Commission No.2133967 A ...... , , 1 41,-z, -i NOT ARY PUOUGCAUFORNIA Signatur-. zak, ,L.„ / 1:2... gt-4.444.---" 121...t.../" .......1......_..RAP 1GE COUNTY / ' kly Cornm.Expos NOVEMBER ii.adl OPTIONAL Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT O INDIVIDUAL O CORPORATE OFFICER TITLE OR TYPE OF DOCUMENT TITLE(S) O PARTNER(S) 0 LIMITED 0 GENERAL NUMBER OF PAGES O ATTORNEY-IN-FACT O TRUSTEE(S) O GUARDIAN/CONSERVATOR O OTHER DATE OF DOCUMENT SIGNER IS REPRESENTING: (NAME OF PERSON(S)OR ENTITY(IES)) SIGNER(S)OTHER THAN NAMED ABOVE 012010006/471643.4 - OALIFORRICIA ALL-PURPOSE A ( ©L LEDEBIT1=Ct' - CRIBL CODE §1189 v-• -..-_-•,---, i--• r i- ----- ,------% -- ' • .....<,..-,-• -•,:.i^!^,- - - -,0--...-4,..-, /— r-•—-.- 4y4 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness,accuracy,or validity of that document State of California y� ) County of (--e•f-lh e-s ) On :Vis•7-I, 7„i er before me, hiiCa�1S'444 tieklizf,A e1.<-1J /fir Z , Bate Herei sert Name and Drle of the Officer personally appeared Cl k ft-C1- c,-i-Ved t - Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person} whose name,(s)a/are subscribed to the within instrument and aclmowledged to me that he/they executed the same in mer/their authorized capacityys, and that by flier/their signature on the instrument the persoyt), or the entity upon behalf of which the perso24 acted, executed the instrument. I certify under PENALTY OF PERJURY under the'laws • of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. •,:x.,, MONICA ISABELA ISORDIA ;_, Notary Public-California � Los Angeles County i ` C"►,/ Commission M 2233154 Signatis • `"' " My Comm.Expires Mar 4,2022 re c Place Notary Seal Above - - OPfOML - - ' Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document Description of Attached Document • Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: - Capacity(ies)Claimed by Signer(s) Signer's Name: Signer's Name: ❑Corporate Officer— Title(s): ❑Corporate Officer —Title(s): D Partner — ❑limited ❑General . ❑Partner— ❑Limited ❑General ❑Individual O Attorney in Fact ❑Individual O Attorney in Fact El Trustee ❑Guardian or Conservator El Trustee ❑Guardian or Conservator ❑Other: , O Other: Signer Is Representing: Signer Is Representing: - e.i�,Aqi,cz!,c�ew.cv-,r--1�... :�c�r�s�eW.�e-- c 4c �.�e�c�:v../e�eLCLe eveceW.v:yavc�c�a�cWcv.vcf 4-,4":.24- ©2016 National Notary Association ''www.NationaiNotary.org' 1-800-US NOTARY(1-800-876-6827) !tern#5907 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy or validity of that document. STATE OF CALIFORNIA COUNTY OF LOS ANGELES On , 2018 before me, , personally appeared , proved to me on the basis of satisfactory evidence to be the person(s) whose names(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature: OPTIONAL Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT LI INDIVIDUAL LI CORPORATE OFFICER TITLE OR TYPE OF DOCUMENT TITLE(S) LI PARTNER(S) LI LIMITED 0 GENERAL NUMBER OF PAGES 0 ATTORNEY-IN-FACT El TRUSTEE(S) 0 GUARDIAN/CONSERVATOR D OTHER DATE OF DOCUMENT SIGNER IS REPRESENTING: (NAME OF PERSON(S)OR ENTITY(IES)) SIGNER(S)OTHER THAN NAMED ABOVE 01203.0006/471643.4 EXHIBIT "A" SCOPE OF SERVICES I. Consultant will perform the following Services: A. Construction inspection of that certain Costal Bluff Fencing Phase II project,which is generally defined as the demolition and disposal of existing fencing and footings, installation of new three rail, colored, precast concrete ranch rail fencing, to be located along the coastal bluff as depicted on the construction location map to be finally determined in the field with the Constractor in three locations, at Abalone Cove Park, Inspiration Point & Portuguese Point, (the "Project") to ensure that the scope of services to be performed by FenceCorp, Inc., a California corporation ("Contractor"), is performed and installed in compliance with Project Plans & Specifications. II. As part of the Services, Consultant will prepare and deliver the following tangible work products to the City: A. Daily inspection reports, including photographs, of scope of work performed by Contractor. B. Summary reports of construction activities of Contractor. C. Summary of Contractor's performance based on the Contractor's weekly schedule. III. In addition to the requirements of Section 6.2, during performance of the Services, Consultant will keep the City updated of the status of performance by delivering the following status reports: A. Summary of weekly construction activities of Contractor. B. Report of weekly Project schedule including 2 week look ahead schedule. IV. All work product is subject to review and acceptance by the City, and must be revised by the Consultant without additional charge to the City until found satisfactory and accepted by City. V. Consultant will utilize the following personnel to accomplish the Services: A. Jim Pugh, Public Works Inspector 01203.0006/471643.4 A-1 EXHIBIT"B" SPECIAL REQUIREMENTS (Superseding Contract Boilerplate) • [INTENTIONALLY LEFT BLANK] 01203.0006/471643.4 B-1 EXHIBIT "C" SCHEDULE OF COMPENSATION I. Consultant shall perform the following Services at the following rates: RAIE TIME TOTAL BUDGET A. Inspection $122/hour* 150 hours $18,300 services (approx. 5 hours/week) *The $122/hour rate shall be inclusive of mileage, equipment, and other incidentals. No overtime is authorized by this Agreement. II. A retention of ten percent (10%) shall be held from each payment as a contract retention to be paid as a part of the final payment upon satisfactory completion of services. NOT APPLICABLE III. Within the budgeted amounts for each Task, and with the approval of the Contract Officer, funds may be shifted from one Task subbudget to another so long as the Contract Sum is not exceeded per Section 2.1, unless Additional Services are approved per Section 2.3. NOT APPLICABLE IV. The City will compensate Consultant for the Services performed upon submission of valid monthly invoices. Each invoice is to include: A. Line items for all the work performed, the number of hours worked, and the hourly rate. B. Line items for all materials and equipment properly charged to the Services. C. Line items for all other approved reimbursable expenses claimed, with supporting documentation. D. Line items for all approved subcontractor labor, supplies, equipment, materials, and travel properly charged to the Services. V. The total compensation for the Services shall not exceed the Contract Sum as provided in Section 2.1 of this Agreement of$18,300.00. VI. Consultant's billing rates for all personnel are attached as Exhibit C-1.NOT APPLICABLE C-1 01203.0006/471643.4 EXHIBIT "D" SCHEDULE OF PERFORMANCE I. Consultant shall perform all services timely in accordance with the following schedule: Days to Perform Hours/week Deadline Date (approx.) A. Inspection 100** 5 Oct 31, 2018 services **Consultant's schedule will track Contractor's construction schedule. H. Consultant shall deliver the following tangible work products to the City by the following dates. A. Daily inspection reports including photographs of work performed, weekly during construction on Monday's. B. Summary reports of construction activities, weekly during construction on Monday's. C. Summary of Contractor's performance based on the Contractor's weekly schedule, weekly during construction on Monday's III. The Contract Officer may approve extensions for performance of the services in accordance with Section 3.2. D-1 01203.0006/471643.4