Loading...
AMG and Associates Inc (Change Order 38)City of Rancho Palos Verdes Department of Public Works 30940 Hawthorne Blvd, Rancho Palos Verdes, CA 90275 (310)544-5252 www.publicworks@rpvca.gov CHANGE ORDER MEMORANDUM TO: RAMZI AWWAD, DIRECTOR OF PUBLIC WORKS FROM: ERIN JONES, GRIFFIN STRUCTURES DATE: JULY 12, 2023 SUBJECT: LADERA LINDA COMMUNITY PARK CONSTRUCTION CHANGE ORDER NUMBER: 38 Description of Construction Change Order This change order is for the cost to add plants along the existing fence on the ocean- facing side of the park per ASI 34. Justification At the December 6, 2022 meeting City Council directed staff to add plants along the park side of the existing ocean-facing fence for screening purposes. Cost for added plants along the new railing added per City Council direction on December 6, 2022 will be processed under a separate change order. Cost Analysis Griffin Structures reviewed the proposal scope and pricing. Reference the attached pricing analysis. Schedule Analysis No time extension was requested by the contractor, and work is expected to be completed within the original construction timeframe. Attachments: Construction Contract Change Order Form Construction Contract Change Order Summary Sheet Contractor’s Change Order Proposals DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A City of Rancho Palos Verdes Department of Public Works 30940 Hawthorne Blvd, Rancho Palos Verdes, CA 90275 (310)544-5252 www.publicworks@rpvca.gov 8405 13 0 0 11 0 0 0 0 0 0 0CO#10 $42,918.80 Working Days 11/09/22 CO#8 $6,437.02 Working Days 09/27/22 CO#9 $1,818.52 Working Days 11/09/22 CO#6 $824.34 Working Days 09/01/22 CO#7 $10,202.36 Working Days 09/27/22 CO#4 $8,558.42 Working Days 09/01/22 CO#5 -$5,378.25 Working Days 09/01/22 CO#2 $12,628.58 Working Days 08/09/22 CO#3 $53,526.25 Working Days 08/31/22 CHANGE ORDER NUMBER COST AMOUNT SCHEDULE EXTENSION DATE CO#1 $54,534.52 Working Days 05/27/22 ORIGINAL COMPLETION DATE:07/27/23 TOTAL SCHEDULE CHANGE ORDERS:Working Days NEW CONTRACT COMPLETION DATE:08/15/23 $1,029,075.00 TOTAL CHANGE ORDERS COST:$759,761.35 NEW CONTRACT AMOUNT:$14,480,761.35 REMAINING CONTINGENCY AMOUNT:$269,313.65 PURCHASE ORDER NUMBER:20220215 ACCOUNT NUMBER:330-400-8405-8403 ORIGINAL CONTRACT AMOUNT:$13,721,000.00 ORIGINAL CONTINGENCY AMOUNT: PREPARED BY:JAMES O'NEILL CONTRACTOR NAME:AMG & Associates, Inc. CONTRACT NUMBER:FY2022-050 CONSTRUCTION CHANGE ORDER SUMMARY SHEET PROJECT NAME:Ladera Linda Community Park DATE:07/12/23 PROJECT CODE: 1 of 2 DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A City of Rancho Palos Verdes Department of Public Works 30940 Hawthorne Blvd, Rancho Palos Verdes, CA 90275 (310)544-5252 www.publicworks@rpvca.gov 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 2 0 0 0 CO # 37 $3,561.51 Working Days 06/16/23 CO #38 $23,527.90 Working Days 07/12/23 CO #35 $3,765.15 Working Days 06/08/23 CO #36 $697.56 Working Days 06/16/23 CO #33 $10,095.54 Working Days 05/31/23 CO #34 $179,119.98 Working Days 06/08/23 CO#31 $2,104.03 Working Days 05/18/23 CO#32 $2,291.43 Working Days 05/19/23 CO#29 $1,055.31 Working Days 05/09/23 CO#30 $3,682.06 Working Days 05/18/23 CO#27 $136,226.21 Working Days 05/03/23 CO#28 $10,819.96 Working Days 05/05/23 CO#25 $8,909.82 Working Days 04/06/23 CO#26 $21,061.12 Working Days 04/25/23 CO#23 $4,094.67 Working Days 02/23/23 CO#24 $19,573.51 Working Days 03/07/23 CO#21 $10,075.07 Working Days 02/21/23 CO#22 $3,178.42 Working Days 02/22/23 CO#19 $17,562.82 Working Days 02/09/23 CO#20 $3,679.17 Working Days 02/16/23 CO#17 $12,582.87 Working Days 02/03/23 CO#18 $16,546.62 Working Days 02/09/23 CO#15 -$3,117.01 Working Days 01/17/23 CO#16 $59,788.90 Working Days 02/02/23 CO#13 $0.00 Working Days 12/30/22 CO#14 -$20,112.42 Working Days 12/30/22 CO#11 $33,868.27 Working Days 12/01/22 CO#12 $9,052.32 Working Days 12/01/22 CHANGE ORDER NUMBER COST AMOUNT SCHEDULE EXTENSION DATE 2 of 2 DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A GRIFFIN STRUCTURES PRICING ANALYSIS - ESTIMATED COST OF WORK ASI 34 - Planting Changes Labor rates are DIR rates and do not include subcontractor burden Equipment rates are CalTrans Description Qty Unit Rate Cost Note Plants - 5-Gallon Ceanothus 226 Each 55.00 12,430.00 Retail average Labor - Planting 226 Each 22.00 4,972.00 RS Means 329333100760 Delivery Fees 1 LS 500.00 500.00 Equipment - Bobcat 24 Hr 35.36 848.64 CalTrans Subtotal 18,750.64 Subtotal Subcontractor Work 18,750.64 Subcontractor Markup 21,563.24 AMG OH&P 1,509.43 AMG Insurance 281.26 AMG Bond 205.41 TOTAL 23,559.34 AS SUBMITTED PCO 59R2 - ASI 34 - Planting Changes MATERIAL LABOR EQUIP QTY Rate Cost QTY Rate Cost Qty Rate Cost 226 5-Gallon Ceanothus Plants 70.94 15820.00 96 58.85 5650.00 0.00 0.00 0.00 0.00 0.00 0.00 0 15820.00 5650.00 0 SUBTOTAL 21,470.00 Sales Tax - Markup SUB SUBCONTRACTOR TOTAL 21,470.00 AMG GCs SUBTOTAL 21,470.00 AMG OH&P 1,502.90 AMG Insurance 322.05 AMG Bond 232.95 TOTAL 23,527.90 DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A City of Rancho Palos Verdes Department of Public Works 30940 Hawthorne Blvd, Rancho Palos Verdes, CA 90275 (310)544-5252 www.publicworks@rpvca.gov 8405 38 0.0 LS 1.0 LS 1.0 LS 0.0 LS 1.0 LS 1.0 LS 0.0 LS 1.0 LS 1.0 LS 0.0 LS 1.0 LS 1.0 LS 0 13 0 NEW CONTRACT AMOUNT:$14,480,761.35 NEW COMPLETION DATE:08/15/23 TOTAL OF CHANGE ORDER #1-37:$736,233.45 TOTAL OF TIME EXTENSIONS #1-37:Working Days TOTAL OF CHANGE ORDER #387:$23,527.90 TOTAL OF TIME EXTENSIONS #37:8 Working Days Totals $23,527.90 0 A TIME EXTENSION OF WORKING DAYS WILL BE ALLOWED FOR THIS WORK ORIGINAL CONTRACT AMOUNT:$13,721,000.00 ORIGINAL COMPLETION DATE:07/27/23 4 012600 AMG Bonding $232.95 $232.95 0 3 012600 AMG Insurance $322.05 $322.05 0 2 012600 AMG Overhead $1,502.90 $1,502.90 0 ADDITIONAL WORKING DAYS 1 329300 AMG PCO 59R2 - ASI 34 - Planting Along Existing Fence $21,470.00 $21,470.00 0 This change order is for the cost to add plants along the existing fence line on the ocean-facing side of the park as directed by City Council on 12/6/22. Reference ASI 34 (revised 7/10/23) and AMG PCO 59R2. SUMMARY OF QUANTITY CHANGES ITEM NO. SPEC CODE DESCRIPTION ORIGINAL QUANTITY NEW QUANTITY QUANTITY DIFFERENCE UNIT PRICE PRICE DIFFERENCE CHANGE ORDER NUMBER:DATE:07/12/23 CONTRACTOR NAME:AMG & Associates, Inc. DESCRIPTION AND LOCATION OF PROPOSED WORK CONSTRUCTION CHANGE ORDER FORM CONTRACT NUMBER:FY2022-050 PROJECT NAME:Ladera Linda Community Park PURCHASE ORDER NUMBER:20220215 PROJECT CODE: DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A City of Rancho Palos Verdes Department of Public Works 30940 Hawthorne Blvd, Rancho Palos Verdes, CA 90275 (310)544-5252 www.publicworks@rpvca.gov 38 Recommended: Erin Jones Date: Construction Manager, Griffin Structures Signature Contractor:Date: Signature City:Date: Signature Date: Public Works Director Signature Ara Mihranian Date: City Manager Signature Lincoln Lo Contract Officer Ramzi Awwad By signing this Change Order, Contractor understands and agrees that it is accepting the specified sums and adjustment of contract time of completion (if any) set forth herein as full, final and complete satisfaction of any and all claims by Contractor for all costs and expenses of Contractor and anyone for whom Contractor may be responsible for the work referred to herein, including but not limited to costs or expenses of the Contractor or any of its subcontractors, materials suppliers, vendors or anyone else for whom Contractor is responsible, for labor, materials, services or equipment, no matter how characterized, whether known or unknown to Contractor, including but not limited to, all field and home office overhead, delay costs/claims, acceleration costs/claims, unabsorbed or under-absorbed home office overhead, extended field costs, general conditions, claim preparation costs, inefficiencies, or the like, no matter how characterized. Contractor further understands and agrees by signing this Change Order that any attempt by Contractor to purportedly reserve rights to claim additional time or compensation for the work referred to herein, is void. Except as set forth, all terms and provisions of the contract and all prior change orders remain in full force and effect. Execution of this Change Order by both parties constitutes a binding agreement. This document constitutes the entire agreement between the parties. The person signing this Change Order for Contractor hereby represents and warrants that he/she is fully authorized to sign this Agreement on behalf of Contractor. Anthony R. Traverso Vice President/Secretary/Treasurer Accepted and Executed by: PURCHASE ORDER NUMBER:20220215 CHANGE ORDER NUMBER:PROJECT CODE:8405 CONTRACTOR NAME:AMG & Associates, Inc. CONSTRUCTION CHANGE ORDER FORM CONTRACT NUMBER:FY2022-050 PROJECT NAME:Ladera Linda Community Park 7/12/23 Anthony R. Traverso Digitally signed by Anthony R. Traverso Date: 2023.07.12 12:16:30 -07'00' DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A 7/31/2023 8/2/2023 8/2/2023 AMG & Associates Inc. 26535 Summit Circle Santa Clarita, California 91350 Phone: (661) 251-7401 Project: 01-22-157 - Ladera Linda Community Center and Park 32201 Forrestal Dr. Rancho Palos Verdes, California 90275 Prime Contract Potential Change Order #059: CE #121 - Bulletin ASI 034 TO: City of Rancho Palos Verdes 30940 Hawthorne Blvd. Rancho Palos Verdes, California 90275 FROM: AMG & Associates, Inc. 26535 Summit Circle Santa Clarita, California 91350 PCO NUMBER/REVISION: 059 / 2  CONTRACT:City Project No. 8405 - Ladera Linda Community Park Project   REQUEST RECEIVED FROM: Martin Blankenship (Bennett Landscape)CREATED BY: Christopher Tumasone (AMG & Associates, Inc.) STATUS: Pending - In Review CREATED DATE: 6/9/2023 REFERENCE: PRIME CONTRACT CHANGE ORDER:  None   FIELD CHANGE: No   LOCATION: ACCOUNTING METHOD: Amount Based   SCHEDULE IMPACT: PAID IN FULL: No   EXECUTED:No SIGNED CHANGE ORDER RECEIVED DATE:   TOTAL AMOUNT: $23,527.90 POTENTIAL CHANGE ORDER TITLE: CE #121 - Bulletin ASI 034 CHANGE REASON: City Bulletin ASI 034 POTENTIAL CHANGE ORDER DESCRIPTION: (The Contract Is Changed As Follows) CE #121 - Bulletin ASI 034 Proposal per bulletin ASI 034.    Owner has requested planting revisions to better conceal the existing fence along the south side of the site to be cut down per ASI 30 and to coordinate with the new fence pathway location clarifications shown in ASI 29.    ATTACHMENTS: LaderaLindaASI034-mb (005).pdf , PCO #059 R1 - ASI 034 Additional Planting.pdf , ASI 34 Planting revisions (1).pdf , PCO #059 Bulletin ASI 034 Planting Revisions.pdf , LaderaLindaASI034-mb.pdf #Budget Code Description Amount 1 02-900.S Landscaping.Commitment planting per ASI 034 $21,470.00 Subtotal:$21,470.00 Overhead (7.00% Applies to all line item types.):$1,502.90 Insurance (1.50% Applies to all line item types.):$322.05 Bonding  (1.00% Applies to all line item types.):$232.95 Grand Total:$23,527.90    City of Rancho Palos Verdes  AMG & Associates, Inc.  30940 Hawthorne Blvd. 26535 Summit Circle    Rancho Palos Verdes, California 90275  Santa Clarita, California 91350             ProcoreArchitectSignHere ProcoreArchitectSignedDate  ProcoreOwnerSignHere ProcoreOwnerSignedDate  ProcoreGeneralContractorSignHere ProcoreGeneralContractorSignedDate SIGNATURE DATE  SIGNATURE DATE  SIGNATURE DATE AMG & Associates Inc.Page 1 of 1 Printed On: 7/11/2023  04:07 PM PCO #059 DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A Page 1 (310) 534-3543, Fax (310) 534-3176 www.bennett-landscape.com Contractors Lic. C27-479003 Certified Pesticide Applicator #30123 Date: Estimate #: Billing:Revised 7/11/23 Job: 661-251-7401 Revised 6/23/23 mb Qty Price Amount 226 21,470.00 (Payment in full is due UPON completion of work unless otherwise arranged prior to start of work.) A Service fee of 1 ½%Pg Subtotal 21,470.00$ percent per month shall be charged on all 30 days past due accounts. In the event this account becomes delinquent and it is necessary to institute legal proceedings, purchaser agrees to pay reasonable attorney's fees and court costs.Tax Total 21,470.00$ LICENSING: Contractor is duly licensed under the law and statues of the State of California. Contractors are required by law to be licensed and regulated by the Contractor's License Board. Any questions concerning a contractor may be referred to the Registrar, Contractor's State License Board, P.O. Box 2600, Sacramento, California 95826 (800) 233-2562 Under the law you may protect yourself against such claims by filling before commencing such work of improvement, an original contract for the work of improvement or a modifica- Under the Mechanics Lien Law, any contractor, subcontractor, laborer, material or other tion thereof, in the office of the county recorder of the county where the property is situated Person who helps to improve your property and is not paid for his labor, services or material,and requiring that a contractor's payment bond be recorded in such office. Said bond shall has a right to enforce his claim against your property. This means that, after a court hearing,an amount not less than fifty percent (50%) of the contract price and shall, in addition to any your property could be sold by a court officer and the proceeds of the sale used to satisfy be in conditions for the performance of the contract, be conditioned for the payment in full the indebtedness. This can happen even if you have paid your own contractor in full, if the of the claims of all persons furnishing labor, services, equipment or materials for the work subcontractor, laborer, or supplier remains unpaid.described in said contract. labor: $5,650.00 4 men x 24 hours "NOTICE TO OWNER" Description LANDSCAPE IMPROVEMENTS AMG & Associates 26535 Summit Circle Santa Clarita, CA 91350 (Section 7018, 7019 - Contractors License Law) 6/8/2023 Ladera Linda Community Center 32201 Forrestal Dr. Rancho Palos Verdes, CA 90275 LaderaLindaASI034-mb Revised 7/10/23 mb Revised 6/13/23 mb add 5 gal Ceanothus 'Dark Star' ASI 034 Planting Changes: material and delivery: $15,820.00 DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A Bulletin ASI 03 4 This Bulletin is issued to define Scope of Revisions/ clarifications to the Drawings and/or Specifications. The Contractor shall carry out the Work in accordance with the following supplemental instructions without change in Contract Sum or Contract Time. Proceeding with the Work in accordance with these instructions indicates your acknowledgment that there will be no change in the Contract Sum or Contract Time. Brief Description of Revisions/ Clarifications: Owner has requested planting revisions to better conceal the existing fence along the south side of the site to be cut down per ASI 30 and to coordinate with the new fence pathway location clarifications shown in ASI 29. See attached drawings for revisions to planting. Attachments: LP1.0 LP1.1 LP1.2 LP1.3 LP3.0 Project LADERA LINDA COMMUNITY CENTER Contract No. 1803 To AMG & ASSOCIATES Office No. No. of Pages 6 Subject Planting Revisions Sender Ingrid Dennert, Johnson Favaro Date 05/5/23 ASI 34 - Revised per RPV Direction on 7/10/23DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A (166354)THEPOINTECORKSCREWNET168365ADVENTURESCAPEDESIGN#2DIRECT BURYONLY(166354)THEPOINTE LLTOPROPETOPROPE UPUPUPMAINT./STORAGEFORRESTAL DRPIR A T E D RDAUNTLESS DRT.O.SHIGH TIERMID TIERLOW TIERxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxNEWCONSTRUCTIONTYPE VOCCUPANCY S-2NEW PARKING AREAPROPERTY LINEPROPERTY LINEPROPERTY LINE PROPERTY L INE PROPERTY L INE 2 5 ' - 0 "xxxxxxxxxxxxxxxxxxxxxxLIM IT OF WORKLIMIT OF WORKLIMIT OF WORKLIMIT OF WORKLIMIT OF WORKxxxxxxxxx xxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxx xxxxxxxxxxxxxxxxxxxxxxxxxxxxx7272******7272******403224168403224168(166354)THEPOINTECORKSCREWNET168365ADVENTURESCAPEDESIGN#2DIRECT BURYONLY(166354)THEPOINTE LLTOPROPETOPROPELIMIT OF WORKLIMIT OF WORK BIMLADERA LINDACOMMUNITY PARK PROJECT:CITY OFRANCHO PALOS VERDES:A r c h i t e c t u r e a n d U r b a n D e s i g n5898 Blackwelder Street, Ground FloorCulver City, CA 90232(Tel) 310-559-5720 (Fax)310-559-8220ARCHITECTCONSULTANTSARCHITECT'S / ENGINEER'S STAMPThe drawings and specifications, ideas, designs, and arrangements are and shallremain the property of the architect. No part thereof shall be copied or used inconnection with any work or project other than the specific project for which theyhave been prepared without the written consent of the architect. Visual contactwith these drawings or specifications shall constitute evidence of acceptance ofthese restrictions.Written dimensions on these drawings shall have precedence over scaleddimensions. Contractor shall verify and be responsible for all dimensions andconditions on the job and this office must be notified of any variation from thedimensions and conditions shown by these drawings. Shop details must besubmitted to this office for approval before proceeding with fabrication.© MDA Johnson Favaro 2017CHECKED BY:ISSUE / REVISIONSNo.IssueDRAWN BY:DateTITLE:SHEET:PROJECT #:DATE:CITY APPROVALSPROJECT32201 Forrestal DriveRancho Palos Verdes, CA 9027530940 Hawthorne Blvd.Rancho Palos Verdes, CA 9027550%DD10.24.19112.28.21100%DD11.13.19250%CD06.01.213SCALE:NNmag. northPERMIT SET12.03.214PERMIT RESUBMITTAL12.28.215PERMIT RESUBMITTAL02.01.226LP1.0OVERALLPLANTING PLANASI 3434A5/5/235/5/2334A34AAdd 226 Total 5-Gallon Ceanothus "Dark Star" along existing fence. Omit Rhus Integrifolia.DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A AMG & Associates Inc. 26535 Summit Circle Santa Clarita, California 91350 Phone: (661) 251-7401 Project: 01-22-157 - Ladera Linda Community Center and Park 32201 Forrestal Dr. Rancho Palos Verdes, California 90275 Bulletin ASI 34 Clarifications TO:Chandra Sutton (AMG & Associates, Inc.) 26535 Summit Circle Santa Clarita, California 91350 FROM:Christopher Tumasone (AMG & Associates, Inc.) 26535 Summit Circle Santa Clarita, California 91355 CREATED DATE:05/18/ 2023 STATUS:Open LOCATION:DUE DATE:06/02/2023 COST CODE:REFERENCE: COST IMPACT:SCHEDULE IMPACT: DRAWING NUMBER:SPEC SECTION: RECEIVED FROM:Martin Blankenship (Bennett Landscape) COPIES TO: Dustin Hartman (AMG & Associates, Inc.), Christopher Tumasone (AMG & Associates, Inc.) SUGGESTION: Question from Christopher Tumasone (AMG & Associates, Inc.) at 09:40 AM on 05/18/2023 After review of ASI 034, it seems that the plant layout around the walk paths have changed from the original design but the quantity of plants on the legend remains the same. Considering how difficult it is to read the very small plant symbols, please confirm the plant count. Attachments: BY DATE COPIES TO AMG & Associates Inc.Page 1 of 1 Printed On: 05/18/2023 09:40 AM RFI #206 See attached updated plant counts. -Jake Patton, KSA 5/25/23 ASI 34, RFI 206 - Revised per RPV Direction on 7/10/23DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A Per bid drawings Add 226 Total 5-Gallon Ceanothus "Dark Star" Omit Rhus Integrifolia CEANOTHUS 'DARK STAR'5 5 DocuSign Envelope ID: BCAE5F8B-9837-4EA3-B526-8FE128A9B89A Certificate Of Completion Envelope Id: BCAE5F8B98374EA3B5268FE128A9B89A Status: Completed Subject: Complete with DocuSign: 8405 Ladera Linda CCO 38_rev1.pdf Source Envelope: Document Pages: 12 Signatures: 3 Envelope Originator: Certificate Pages: 5 Initials: 1 Lincoln Lo AutoNav: Enabled EnvelopeId Stamping: Enabled Time Zone: (UTC-08:00) Pacific Time (US & Canada) 30940 Hawthorne Blvd. Rancho Palos Verdes, CA 90275 llo@rpvca.gov IP Address: 47.147.134.144 Record Tracking Status: Original 7/31/2023 10:05:26 AM Holder: Lincoln Lo llo@rpvca.gov Location: DocuSign Signer Events Signature Timestamp Lincoln Lo llo@rpvca.gov Public Works Deputy Director City of Rancho Palos Verdes Security Level: Email, Account Authentication (None) Signature Adoption: Pre-selected Style Using IP Address: 47.147.134.144 Sent: 7/31/2023 10:12:27 AM Viewed: 7/31/2023 10:12:50 AM Signed: 7/31/2023 10:13:55 AM Electronic Record and Signature Disclosure: Not Offered via DocuSign Ramzi Awwad rawwad@rpvca.gov Director of Public Works City of Rancho Palos Verdes Security Level: Email, Account Authentication (None) Signature Adoption: Drawn on Device Using IP Address: 72.34.97.146 Sent: 7/31/2023 10:14:00 AM Viewed: 8/2/2023 5:00:29 PM Signed: 8/2/2023 5:00:48 PM Electronic Record and Signature Disclosure: Accepted: 3/2/2023 10:45:19 AM ID: 3242b72d-4755-489d-8e5f-7c62dc360470 Vina Ramos vramos@rpvca.gov Deputy Director of Finance City of Rancho Palos Verdes Security Level: Email, Account Authentication (None) Signature Adoption: Pre-selected Style Using IP Address: 107.127.56.60 Signed using mobile Sent: 8/2/2023 5:00:54 PM Viewed: 8/2/2023 5:09:14 PM Signed: 8/2/2023 5:11:51 PM Electronic Record and Signature Disclosure: Not Offered via DocuSign Ara Mihranian aram@rpv.com Security Level: Email, Account Authentication (None) Signature Adoption: Uploaded Signature Image Using IP Address: 72.34.97.146 Sent: 8/2/2023 5:11:57 PM Viewed: 8/2/2023 7:35:51 PM Signed: 8/2/2023 7:36:28 PM Electronic Record and Signature Disclosure: Accepted: 8/2/2023 7:35:51 PM ID: 2b80e057-31b9-4b94-b4bf-a5941350573d In Person Signer Events Signature Timestamp Editor Delivery Events Status Timestamp Agent Delivery Events Status Timestamp Intermediary Delivery Events Status Timestamp Certified Delivery Events Status Timestamp Carbon Copy Events Status Timestamp James O'Neill joneill@rpvca.gov Project Manager (PW) City of Rancho Palos Verdes Security Level: Email, Account Authentication (None) Sent: 7/31/2023 10:12:26 AM Viewed: 8/2/2023 4:15:27 PM Electronic Record and Signature Disclosure: Not Offered via DocuSign Erin Jones ejones@griffinstructures.com Security Level: Email, Account Authentication (None) Sent: 8/2/2023 7:36:35 PM Electronic Record and Signature Disclosure: Not Offered via DocuSign Lorna Cloke lornac@rpvca.gov Security Level: Email, Account Authentication (None) Sent: 8/2/2023 7:36:37 PM Electronic Record and Signature Disclosure: Not Offered via DocuSign City Clerk cityclerk@rpvca.gov Security Level: Email, Account Authentication (None) Sent: 8/2/2023 7:36:39 PM Viewed: 8/3/2023 7:35:04 AM Electronic Record and Signature Disclosure: Accepted: 2/1/2023 3:10:58 PM ID: 505eed45-7ed0-4db8-aae6-ef6eedfef03d Witness Events Signature Timestamp Notary Events Signature Timestamp Envelope Summary Events Status Timestamps Envelope Sent Hashed/Encrypted 7/31/2023 10:12:26 AM Certified Delivered Security Checked 8/2/2023 7:35:51 PM Signing Complete Security Checked 8/2/2023 7:36:28 PM Completed Security Checked 8/2/2023 7:36:39 PM Payment Events Status Timestamps Electronic Record and Signature Disclosure ELECTRONIC RECORD AND SIGNATURE DISCLOSURE From time to time, City of Rancho Palos Verdes (we, us or Company) may be required by law to provide to you certain written notices or disclosures. Described below are the terms and conditions for providing to you such notices and disclosures electronicall y through the DocuSign system. Please read the information below carefully and thoroughly, and if you can access this information electronically to your satisfaction and agree to this Electronic Record and Signature Disclosure (ERSD), please confirm your agreement by selecting the check-box next to ‘I agree to use electronic records and signatures’ before clicking ‘CONTINUE’ within the DocuSign system. Getting paper copies At any time, you may request from us a paper copy of any record provided or made av ailable electronically to you by us. You will have the ability to download and print documents we send to you through the DocuSign system during and immediately after the signing session and, if you elect to create a DocuSign account, you may access the documents for a limited period of time (usually 30 days) after such documents are first sent to you. After such time, if you wish for us to send you paper copies of any such documents from our office to you, you will be charged a $0.00 per-page fee. You may request delivery of such paper copies from us by following the procedure described below. Withdrawing your consent If you decide to receive notices and disclosures from us electronically, you may at any time change your mind and tell us that thereafter you want to receive required notices and disclosures only in paper format. How you must inform us of your decision to receive future notices and disclosure in paper format and withdraw your consent to receive notices and disclosures electronically is described below. Consequences of changing your mind If you elect to receive required notices and disclosures only in paper format, it will slow the speed at which we can complete certain steps in transactions with you and delivering services to you because we will need first to send the required notices or disclosures to you in paper format, and then wait until we receive back from you your acknowledgment of your receipt of such paper notices or disclosures. Further, you will no longer be able to use the DocuSign system to receive required notices and consents electronically from us or to sign electronically documents from us. All notices and disclosures will be sent to you electronically Electronic Record and Signature Disclosure created on: 6/15/2021 5:55:39 PM Parties agreed to: Ramzi Awwad, Ara Mihranian, City Clerk Unless you tell us otherwise in accordance with the procedures described herein, we will provide electronically to you through the DocuSign system all required notices, disclosures, authorizations, acknowledgements, and other documents that are required to be provided or made available to you during the course of our relationship with you. To reduce the chance of you inadvertently not receiving any notice or disclosure, we prefer to provide all of the required notices and disclosures to you by the same method and to the same address that you have given us. Thus, you can receive all the disclosures and notices electronically or in paper format through the paper mail delivery system. If you do not agree with this process, please let us know as described below. Please also see the paragraph immediately above that describes the consequences of your electing not to receive delivery of the notices and disclosures electronically from us. How to contact City of Rancho Palos Verdes: You may contact us to let us know of your changes as to how we may contact you electronically, to request paper copies of certain information from us, and to withdraw your prior consent to receive notices and disclosures electronically as follows: To contact us by email send messages to: terit@rpvca.gov To advise City of Rancho Palos Verdes of your new email address To let us know of a change in your email address where we should send notices and disclosures electronically to you, you must send an email message to us at terit@rpvca.gov and in the body of such request you must state: your previous email address, your new email address. We do not require any other information from you to change your email address. If you created a DocuSign account, you may update it with your new email address through your account preferences. To request paper copies from City of Rancho Palos Verdes To request delivery from us of paper copies of the notices and disclosures previously provided by us to you electronically, you must send us an email to terit@rpvca.gov and in the body of such request you must state your email address, full name, mailing address, and telephone number. We will bill you for any fees at that time, if any. To withdraw your consent with City of Rancho Palos Verdes To inform us that you no longer wish to receive future notices and disclosures in electronic format you may: i. decline to sign a document from within your signing session, and on the subsequent page, select the check-box indicating you wish to withdraw your consent, or you may; ii. send us an email to terit@rpvca.gov and in the body of such request you must state your email, full name, mailing address, and telephone number. We do not need any other information from you to withdraw consent.. The consequences of your withdrawing consent for online documents will be that transactions may take a longer time to process.. Required hardware and software The minimum system requirements for using the DocuSign system may change over time. The current system requirements are found here: https://support.docusign.com/guides/signer-guide- signing-system-requirements. Acknowledging your access and consent to receive and sign documents electronically To confirm to us that you can access this information electronically, which will be similar to other electronic notices and disclosures that we will provide to you, please confirm that you have read this ERSD, and (i) that you are able to print on paper or electronically save this ERSD for your future reference and access; or (ii) that you are able to email this ERSD to an email address where you will be able to print on paper or save it for your future reference and access. Further, if you consent to receiving notices and disclosures exclusively in electronic format as described herein, then select the check-box next to ‘I agree to use electronic records and signatures’ before clicking ‘CONTINUE’ within the DocuSign system. By selecting the check-box next to ‘I agree to use electronic records and signatures’, you confirm that:  You can access and read this Electronic Record and Signature Disclosure; and  You can print on paper this Electronic Record and Signature Disclosure, or save or send this Electronic Record and Disclosure to a location where you can print it, for future reference and access; and  Until or unless you notify City of Rancho Palos Verdes as described above, you consent to receive exclusively through electronic means all notices, disclosures, authorizations, acknowledgements, and other documents that are required to be provided or made available to you by City of Rancho Palos Verdes during the course of your relationship with City of Rancho Palos Verdes.