Loading...
AMG and Associates Inc (Change Order 27)City of Rancho Palos Verdes Department of Public Works 30940 Hawthorne Blvd, Rancho Palos Verdes, CA 90275 (310)544-5252 www.publicworks@rpvca.gov CHANGE ORDER MEMORANDUM TO: RAMZI AWWAD, DIRECTOR OF PUBLIC WORKS FROM: ERIN JONES, GRIFFIN STRUCTURES DATE: MAY 8, 2023 SUBJECT: LADERA LINDA COMMUNITY PARK CONSTRUCTION CHANGE ORDER NUMBER: 27 Description of Construction Change Order This change order is for the cost to add a post and cable railing next to the pathways along the ocean-facing side of the park per ASI 29. Justification At the December 6, 2022 meeting City Council directed staff to install a context- sensitive railing at a height between 36 and 42 inches adjacent to the walking paths along the entire ocean-facing side of the park. Cost Analysis Griffin Structures reviewed the proposal scope and pricing. In addition, the Contractor obtained three quotes for the added railing. Reference the attached pricing analysis. Schedule Analysis No time extension was requested by the contractor, and work is expected to be completed within the original construction timeframe. Attachments: Construction Contract Change Order Form Construction Contract Change Order Summary Sheet Contractor’s Change Order Proposal DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 City of Rancho Palos Verdes Department of Public Works 30940 Hawthorne Blvd, Rancho Palos Verdes, CA 90275 (310)544-5252 www.publicworks@rpvca.gov 8405 11 0 0 11 0 0 0 0 0 0 0CO#10 $42,918.80 Working Days 11/09/22 CO#8 $6,437.02 Working Days 09/27/22 CO#9 $1,818.52 Working Days 11/09/22 CO#6 $824.34 Working Days 09/01/22 CO#7 $10,202.36 Working Days 09/27/22 CO#4 $8,558.42 Working Days 09/01/22 CO#5 -$5,378.25 Working Days 09/01/22 CO#2 $12,628.58 Working Days 08/09/22 CO#3 $53,526.25 Working Days 08/31/22 CHANGE ORDER NUMBER COST AMOUNT SCHEDULE EXTENSION DATE CO#1 $54,534.52 Working Days 05/27/22 ORIGINAL COMPLETION DATE:07/27/23 TOTAL SCHEDULE CHANGE ORDERS:Working Days NEW CONTRACT COMPLETION DATE:08/11/23 $1,029,075.00 TOTAL CHANGE ORDERS COST:$519,040.92 NEW CONTRACT AMOUNT:$14,240,040.92 REMAINING CONTINGENCY AMOUNT:$510,034.08 PURCHASE ORDER NUMBER:20220215 ACCOUNT NUMBER:330-400-8405-8403 ORIGINAL CONTRACT AMOUNT:$13,721,000.00 ORIGINAL CONTINGENCY AMOUNT: PREPARED BY:JAMES O'NEILL CONTRACTOR NAME:AMG & Associates, Inc. CONTRACT NUMBER:FY2022-050 CONSTRUCTION CHANGE ORDER SUMMARY SHEET PROJECT NAME:Ladera Linda Community Park DATE:05/03/23 PROJECT CODE: 1 of 2 DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 5/11/2023 City of Rancho Palos Verdes Department of Public Works 30940 Hawthorne Blvd, Rancho Palos Verdes, CA 90275 (310)544-5252 www.publicworks@rpvca.gov 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 CO#29 Working Days CO#30 Working Days CO#27 $136,226.21 Working Days 05/03/23 CO#28 Working Days CO#25 $8,909.82 Working Days 04/06/23 CO#26 $21,061.12 Working Days 04/25/23 CO#23 $4,094.67 Working Days 02/23/23 CO#24 $19,573.51 Working Days 03/07/23 CO#21 $10,075.07 Working Days 02/21/23 CO#22 $3,178.42 Working Days 02/22/23 CO#19 $17,562.82 Working Days 02/09/23 CO#20 $3,679.17 Working Days 02/16/23 CO#17 $12,582.87 Working Days 02/03/23 CO#18 $16,546.62 Working Days 02/09/23 CO#15 -$3,117.01 Working Days 01/17/23 CO#16 $59,788.90 Working Days 02/02/23 CO#13 $0.00 Working Days 12/30/22 CO#14 -$20,112.42 Working Days 12/30/22 CO#11 $33,868.27 Working Days 12/01/22 CO#12 $9,052.32 Working Days 12/01/22 CHANGE ORDER NUMBER COST AMOUNT SCHEDULE EXTENSION DATE 2 of 2 DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 PRICING ANALYSIS - ESTIMATED COST OF WORK ASI 29 - Add Post & Cable Fence per City Council Direction AS SUBMITTED AMG PCO 47R - ASI 29 - Add Post & Cable Fence per City Council Direction Five Star Fence Proposal 4/26/23 QTY (LF)Rate Cost 1050 118.39 124311.00 0.00 124311.00 SUBTOTAL with MARKUP 124,311.00 AMG OH&P 8,701.77 AMG Insurance 1,864.67 AMG Bond 1,348.77 TOTAL 136,226.21 129.74 COST PER LF WITH SUB & GC MARKUPS Johnson Favaro - 4/26/23 Updated ROM with Stainless Steel Cabling QTY Unit Rate Cost Posts 1 3200.00 3200.00 Stainless Steel Cable (per 500' reel)13 603.08 7840.00 Concrete Footing 132 500 66000.00 Labor 1050 30.00 31500.00 1050 103.37 108540.00 SUBTOTAL with Subcontractor MARKUP 124,821.00 AMG OH&P 8,737.47 AMG Insurance 1,872.32 AMG Bond 1,354.31 TOTAL 136,785.09 130.27 COST PER LF WITH SUB & GC MARKUPS Alternate Quotes received by AMG for Comparison Act 1 Construction QTY (LF)Rate Cost 1050 145.25 152510.00 0.00 152510.00 SUBTOTAL with MARKUP 152,510.00 AMG OH&P 10,675.70 AMG Insurance 2,287.65 AMG Bond 1,654.73 TOTAL 167,128.08 159.17 COST PER LF WITH SUB & GC MARKUPS Bennett Landscape QTY Rate Cost 1050 130.54 137070.00 0.00 137070.00 SUBTOTAL with MARKUP 137,070.00 AMG OH&P 9,594.90 AMG Insurance 2,056.05 AMG Bond 1,487.21 TOTAL 150,208.16 143.06 COST PER LF WITH SUB & GC MARKUPS Cable Rail Fence Comparison Pricing DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 1 Erin Jones From:Ingrid Dennert <idennert@johnsonfavaro.com> Sent:Wednesday, April 26, 2023 3:01 PM To:Erin Jones Subject:New cable rail fence pricing Hi Erin, I went back and updated the ROM we got from the estimator with the new stainless steel cable rail material cost and end up with about $120K. I don’t know shipping costs so not included. Curious to see where the ROM differs with the estimates AMG is getting. Posts Material cost (from Cedar Fence Direct): $3200 Monofilament line material cost (From Finishline XL fencing): $1500 (13) reels of 500ft stainless steel cable: $7840 Fence with stainless steel cable Cost before markups not including shipping: 3200+7840+66,000+31,500 = 108,540 + $10,311 markups = $118,851 (materials shipping not figured in) Cable Rail Fence Comparison Pricing DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 2 INGRID DENNERT ASSOCIATE PRINCIPAL, ARCHITECT 5898 BLACKWELDER STREET CULVER CITY, CA 90232 T: 310.559.5720 | F: 310.559.8220 http://www.johnsonfavaro.com idennert@johnsonfavaro.com Cable Rail Fence Comparison Pricing DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 Ladera Linda Cable Fencing ACT 1 Construction, Inc. Date: 4/13/23 P.O. Box 5087 To: Dustin Hartman Norco, CA, 92860 Company: AMG & Associates P: 951-735-1184 F: 951-737-5342 CA License: #657517 Project Ladera Linda Community Park ESTIMATOR Alex Witham ITEM # DESCRIPTION UNIT OF MEASURE EST UNIT PRICE EXT PRICE 1 Furnish and install 1,065’ LF of 42’’ High stainless steel cable fence with 5’’ diameter PDTF Wood Post. Per detail 4,5,6&7 on plan sheet A1.07F provided in ASI 29 LS 1 $151,000.00 $151,000.00 2 Bond Premium % 1% $1,510.00 $1,510.00 3 Exclusions: Staking, grading, spoils removal, core drilling, saw cutting, placement of sleeves or ground track, damage to underground utilities or impact of, damage to irrigation, underground radar scanning for utilities, clearing, grubbing, damage to landscape, concrete flatwork of any kind, patch back of any kind, temporary fence, grounding, structural calculations, engineering, signage, knox box or knox pad locks, permits, permit fees, special inspections fees. Cable Rail Fence Comparison Pricing DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 4 Total $152,510.00 Exclusions: · Damage to underground lines not clearly marked and shown to contractor prior to start of excavation. · Removal or disposal of any foreign or deleterious materials encountered during excavation or objects, either natural or man-made, larger than 2’x2’ which require a breaker. · Cost or responsibility of any surveying, soils testing, or engineering test of any type. · Responsibility for conditions to hardscape as a result of improper sub base or lack of compaction, unless compaction and/or installation of sub base are quoted in this proposal. · Any damage to any concrete or asphalt in order to obtain access to working area. · Any item not specifically listed above. * Concrete is a combination of natural and man-made materials which can result in slight variations, although we take every measure to prevent it, cracking can naturally occur and we make no warranties against it. We propose to furnish material and labor, complete in accordance with above specifications, for the sum of: One Hundred Fifty Two Thousand Five Hundred Ten Dollars and 00/100 Dollars $ $152.510.00 Cable Rail Fence Comparison Pricing DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 Payments to be made as follows: As invoiced per contract Contractor’s signature: Alex Witham. Acceptance of proposal: The above price, specifications and conditions are satisfactory and are hereby accepted. You are authorized to do the work as specified. Payment will be made as outlined above. Owner’s signature: Date: Cable Rail Fence Comparison Pricing DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 Page 1 (310) 534-3543, Fax (310) 534-3176 www.bennett-landscape.com Contractors Lic. C27-479003 Certified Pesticide Applicator #30123 Date: Estimate #: Billing:Job: Qty Price Amount 1,070 137,070.00 Labor - 225 hrs x $150/hr = $33,750.00 supervision - 225 hrs x $100/hr = $22,500.00 auger and operator - $21,670.00 Material Cost - $46,760 + 15% markup $7,014 + tax $5,376 (Payment in full is due UPON completion of work unless otherwise arranged prior to start of work.) A Service fee of 1 ½%Pg Subtotal 137,070.00$ percent per month shall be charged on all 30 days past due accounts. In the event this account becomes delinquent and it is necessary to institute legal proceedings, purchaser agrees to pay reasonable attorney's fees and court costs.Tax Total 137,070.00$ LICENSING: Contractor is duly licensed under the law and statues of the State of California. Contractors are required by law to be licensed and regulated by the Contractor's License Board. Any questions concerning a contractor may be referred to the Registrar, Contractor's State License Board, P.O. Box 2600, Sacramento, California 95826 (800) 233-2562 Under the law you may protect yourself against such claims by filling before commencing such work of improvement, an original contract for the work of improvement or a modifica- Under the Mechanics Lien Law, any contractor, subcontractor, laborer, material or other tion thereof, in the office of the county recorder of the county where the property is situated Person who helps to improve your property and is not paid for his labor, services or material,and requiring that a contractor's payment bond be recorded in such office. Said bond shall has a right to enforce his claim against your property. This means that, after a court hearing,an amount not less than fifty percent (50%) of the contract price and shall, in addition to any your property could be sold by a court officer and the proceeds of the sale used to satisfy be in conditions for the performance of the contract, be conditioned for the payment in full the indebtedness. This can happen even if you have paid your own contractor in full, if the of the claims of all persons furnishing labor, services, equipment or materials for the work subcontractor, laborer, or supplier remains unpaid.described in said contract. installations. Unless stated otherwise at time of delivery, all goods are accepted in good DIR Registration # 1000006863 Engineer Survey Excluded 1/4", 1x9 Type 316 stainless steel cable - ends to be made-up with We remove any debris generated from our work. However, we are not Approvals Excluded responsible for damage due to hidden conditions. Especially under ground x__________________________________ Date:____________________ Notes: Prevailing Wage Job accordingly. Yes, I acknowledge the above scope of work. I have signed and Progress payments are due upon completion of individual tasks. "NOTICE TO OWNER" dated this form giving permission to proceed. You may bill me Description LANDSCAPE IMPROVEMENTS AMG & Associates (Section 7018, 7019 - Contractors License Law) 3/28/2023 Ladera Linda Community Center LaderaLindaASI29-mb This Quote Is Effective For 10 Days labor and material subtotal: Material - $59,150.00 ASI 29 Permits Excluded Ultra-Tec Invisiware Radius Ferrule's New Fencing: Lf. 42" tall post and cable fencing - use pressure treated 5 1/2" x 5 1/2" This Is A Unit Based Quotation square posts w/ (5 each) 1/2" holes drilled to carry stainless steel cable, condition and in the proper quantity and quality. Cable Rail Fence Comparison Pricing DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 City of Rancho Palos Verdes Department of Public Works 30940 Hawthorne Blvd, Rancho Palos Verdes, CA 90275 (310)544-5252 www.publicworks@rpvca.gov 8405 27 0.0 LS 1.0 LS 1.0 LS 0.0 LS 1.0 LS 1.0 LS 0.0 LS 1.0 LS 1.0 LS 0.0 LS 1.0 LS 1.0 LS 0 11 0 NEW CONTRACT AMOUNT:$14,240,040.92 NEW COMPLETION DATE:08/11/23 TOTAL OF CHANGE ORDER #1-26:$382,814.71 TOTAL OF TIME EXTENSIONS #1-26:Working Days TOTAL OF CHANGE ORDER #27:$136,226.21 TOTAL OF TIME EXTENSIONS #27:Working Days Totals $136,226.21 0 A TIME EXTENSION OF WORKING DAYS WILL BE ALLOWED FOR THIS WORK ORIGINAL CONTRACT AMOUNT:$13,721,000.00 ORIGINAL COMPLETION DATE:07/27/23 4 012600 AMG Bonding $1,348.77 $1,348.77 0 3 012600 AMG Insurance $1,864.67 $1,864.67 0 2 012600 AMG Overhead $8,701.77 $8,701.77 0 ADDITIONAL WORKING DAYS 1 323113 AMG PCO 47R1 - Add post and cable railing per ASI 29 $124,311.00 $124,311.00 0 This change order is for the cost to add a post and cable railing next to the pathways along the ocean-facing side of the park as directed by City Council on 12/6/22. Reference ASI 29 and AMG PCO 47R1. SUMMARY OF QUANTITY CHANGES ITEM NO. SPEC CODE DESCRIPTION ORIGINAL QUANTITY NEW QUANTITY QUANTITY DIFFERENCE UNIT PRICE PRICE DIFFERENCE CHANGE ORDER NUMBER:DATE:05/03/23 CONTRACTOR NAME:AMG & Associates, Inc. DESCRIPTION AND LOCATION OF PROPOSED WORK CONSTRUCTION CHANGE ORDER FORM CONTRACT NUMBER:FY2022-050 PROJECT NAME:Ladera Linda Community Park PURCHASE ORDER NUMBER:20220215 PROJECT CODE: DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 5/10/2023 5/10/2023 5/11/2023 AMG & Associates Inc. 26535 Summit Circle Santa Clarita, California 91350 Phone: (661) 251-7401 Project: 01-22-157 - Ladera Linda Community Center and Park 32201 Forrestal Dr. Rancho Palos Verdes, California 90275 Prime Contract Potential Change Order #047: CE #066 - Bulletin ASI 29 - Cable Rail Fence TO: City of Rancho Palos Verdes 30940 Hawthorne Blvd. Rancho Palos Verdes, California 90275 FROM: AMG & Associates, Inc. 26535 Summit Circle Santa Clarita, California 91350 PCO NUMBER/REVISION: 047 / 1  CONTRACT:City Project No. 8405 - Ladera Linda Community Park Project   REQUEST RECEIVED FROM: Christopher Tumasone (AMG & Associates, Inc.) CREATED BY: Christopher Tumasone (AMG & Associates, Inc.) STATUS: Pending - In Review CREATED DATE: 4/18/2023 REFERENCE: PRIME CONTRACT CHANGE ORDER:  None   FIELD CHANGE: No   LOCATION: ACCOUNTING METHOD: Amount Based   SCHEDULE IMPACT: PAID IN FULL: No   EXECUTED:No SIGNED CHANGE ORDER RECEIVED DATE:   TOTAL AMOUNT: $136,226.21 POTENTIAL CHANGE ORDER TITLE: CE #066 - Bulletin ASI 29 - Cable Rail Fence CHANGE REASON: Bulletin ASI 29 POTENTIAL CHANGE ORDER DESCRIPTION: (The Contract Is Changed As Follows) CE #066 - Bulletin ASI 29 - Cable Rail Fence This change event covers the cost for a new fence/rail along the walk paths. 42" high railing, 1,050 LF.  ATTACHMENTS: 5 star quote.pdf , PCO #047 - Bulletin ASI 29 Cable Rail Fence.pdf , JF- Bulletin ASI29.pdf , Erin Jones_Ladera Linda - Request for Pricing - New Fence_Rail along Walking Paths.pdf , A1.02 Proposed Site Plan - New 42-inch barrier.pdf , Renderings of Post & Cable Fence.pdf , Post & Cable Fence Product.pdf #Budget Code Description Amount 1 02-900.S Landscaping.Commitment proposal per ASI 29 $124,311.00 Subtotal:$124,311.00 Overhead (7.00% Applies to all line item types.):$8,701.77 Insurance (1.50% Applies to all line item types.):$1,864.67 Bonding  (1.00% Applies to all line item types.):$1,348.77 Grand Total:$136,226.21    City of Rancho Palos Verdes  AMG & Associates, Inc.  30940 Hawthorne Blvd. 26535 Summit Circle    Rancho Palos Verdes, California 90275  Santa Clarita, California 91350             ProcoreArchitectSignHere ProcoreArchitectSignedDate  ProcoreOwnerSignHere ProcoreOwnerSignedDate  ProcoreGeneralContractorSignHere ProcoreGeneralContractorSignedDate SIGNATURE DATE  SIGNATURE DATE  SIGNATURE DATE AMG & Associates Inc.Page 1 of 1 Printed On: 4/26/2023  12:16 PM PCO #047 DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 PROPOSAL AND CONTRACT State Cont. Lic # 1022201 DIR # 1000915726, SBE 13477 Louvre St Pacoima, CA, 91331 Tel: (818) 890-0500 Fax: (818) 890-0511 www.fivestarfences.com Attn:Date: April 26, 2023 TO:Ladera Linda Community Park Project Tel: From: Jonathan Cervantes Cell: 310 508 4320 JonathanC@fivestarfences.com Line Item Plan Reference Linear Foot. Qty (ea)Lump Sum Unit $ unit M $ 6,312 1 1185 1 HAAS SS 1/4" x 500' Type 316SS Cable $ 117,999 $ 100 LF 1/A1.05B 243 1 1/A1.06B 444 1 1/A1.07B 498 1 Acknowledgement: Plan/Spec/JF-Bulletin ASI29 Exclusions: 1) Construction debris/waste haul away 200' from working area. 3) Removal and disposal of installed temporary fence/gate at termination of project. 4) Sign and/or signage installation. 5) Paint/Stain and/or painting unless explicitly specified in bid proposal. Quote No. 042623LLCRF 32201 Forrestal Drive Estimator 6&7/A1/07F Rancho Palos Verdes, CA 90275 The following information outlines the scope of work we intend to bid or provide for this project and our preliminary take off estimates. Please advise us if you see any discrepancies, require other items of interest or have additional needs, information or addenda. Mobilization 3'-6"H Cable Rail Fence (6-Cable) Posts: 5"x5"x 6'-6"L Trased Wood Fence Post set in 12"x42"deep concrete footings Ends: Ultra-Tec Invisiware Radius Ferrule (RF-8) w/ SS Washer Five Star Fence is allowed to adjust the unit price effective January 1st of each year following the year the original contract for inflation. This annual price adjustment will be based on the average Iron & Steel PPI (Producer Price Index) as published by U.S. Bureau of Labor Statistics during the immediate preceding year. For example, if the contract is entered into during 2021, the first adjustment will be January 1st 2022 for average steel price increases as published by PPI for 2021. The Second adjustment will be January 1st 2023 for steel price increase by PPI for 2022 and so on. There will be no adjustment if price increase is less than 3%. Any adjustment will be capped at 10% maximum. Billed work before adjustments are not subject to change. 124,311$ Notes: Price subject to change is material changes from above description. 2) Work on Restricted and/or impaired site area not accessible to construction vehicles and equipment, or restricted access due to power line and/or existing obstacles. BASE PRICE per above itemized scope : DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 PROPOSAL AND CONTRACT State Cont. Lic # 1022201 DIR # 1000915726, SBE 13477 Louvre St Pacoima, CA, 91331 Tel: (818) 890-0500 Fax: (818) 890-0511 www.fivestarfences.com Attn:Date: April 26, 2023 TO:Ladera Linda Community Park Project Tel: From: Jonathan Cervantes Cell: 310 508 4320 JonathanC@fivestarfences.com Quote No. 042623LLCRF 32201 Forrestal Drive Estimator Rancho Palos Verdes, CA 90275 The following information outlines the scope of work we intend to bid or provide for this project and our preliminary take off estimates. Please advise us if you see any discrepancies, require other items of interest or have additional needs, information or addenda. 6) Electrical components, low voltage components, wiring or cabling on any fence/gates. 8) Deputy Inspector, Permit, Fees & Engineering. 13) Setting post/railing sleeves in footing holes or CMU. 14) Move-in of work less than $2,500 billable value. 15) Temporary Fencing or any site security during construction unless explicitly specified in bid proposal. 16) Any work not listed in the above bid. Price based on Prevailing Wages YES (Y/N) Perf/paym Bond included?NO (Y/N) BASE BID:$124,311 10) Saw cut and patch back to concrete/asphalt along fence line. repair to sidewalks & slabs unavoidably damaged during installation of fences/gates/netting. 11) Removal of foreign objects, including utility, existing footings, metal objects other than soil, along and under fence line by others. 12) Underground Utility Scan, Post tension cable scan, repair&restore underground damage if no clear "ALERT/WARNING" sign on footing locations. Estimate expires after 30 days. Total Contract Price To Be: Lump Sum Owner to initial 7) Mow strips, curbs, pilasters, pylons, stone columns, CMU and any concrete work except fence/gate post setting. 9) Removal of landscaping (including roots & trees lower than fence height) & within 3 ft each side of fence line. Repair to and/or recovery of landscape damaged during installation of fences/gates/netting. DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 Bulletin ASI 029 This Bulletin is issued to define Scope of Revisions/ clarifications to the Drawings and/or Specifications. The Contractor shall carry out the Work in accordance with the following supplemental instructions without change in Contract Sum or Contract Time. Proceeding with the Work in accordance with these instructions indicates your acknowledgment that there will be no change in the Contract Sum or Contract Time. Brief Description of Revisions/ Clarifications: City elected to add a cable rail fence along the south edge of pathways as shown in the attached revised plans. Additionally, enlarged dimension plans are being provided to locate pathway intersections. A revised planting plan with upsized plantings will be issued under separate ASI. Attachments: A1.02B – SITE PLAN – PERIMETER FENCING A1.05B – HIGH TIER PERIMETER FENCING DIMENSION PLAN A1.06B – MID TIER PERIMETER FENCING DIMENSION PLAN A1.07B – LOW TIER PERIMETER FENCING DIMENSION PLAN A1.07C – PERIMETER FENCING ENLAGED PLANS A1.07F – PERIMETER FENCING PLANS AND DETAILS Project LADERA LINDA COMMUNITY CENTER Contract No. 1803 To AMG & ASSOCIATES Office No. No. of Pages 7 Subject Perimeter Fencing at Path Edge Sender Ingrid Dennert, Johnson Favaro Date 03/07/23 DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 7272* * ** * *487272* * ** * *48403224168403224168UPFORRESTAL DRPIRATE DRDAUNTLESS DRT.O.SHIGH TIERMID TIER LOW TIERxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxNEW PARKING AREAPROPERTY LINEPROPERTY LINEPROPERTY LINEPROPERTY LINEPROPERTY LINE25' - 0"xxxxxxxxxxxxxxxxxxxxxxLIMIT OF WORKLIMIT OF WORKLIMIT OF WORKLIMIT OF WORKLIMIT OF WORKxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxA1.05B1A1.06B1A1.07B1A1.07C129A29AXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXLEGENDPARTIALLY PLANTED ZONE, REFERENCE A1.07FWIRE CABLE FENCESTORM DRAIN PER CIVILCLEAR PATH ZONE, REFERENCE A1.07FBIOSWALESEE CIVIL AND LANDSCAPE DWGSIRRIGATED GRASS LAWNSEE LANDSCAPE DWGSDECOMPOSED GRANITE, DG-1, REFER TO 8/LP2.0LEGENDPROPERTY LINECOASTAL SAGE SCRUB, SEE LANDSCAPE DWGSGRAVEL, GR-1, REFER TO 8/LP2.0EXISTING FENCE TO REMAINFNC 1: CHAINLINK FENCING/GATES; 6 'HCOASTAL NATIVE WILDFLOWERS, SEE LANDSCAPE DWGSCOMPACTED DIRTENGINEERED WOOD FIBRE PLAY SURFACING, EWF-1BASKETBALL SPORTS COATING ON CONCRETE, SPC-1PERVIOUS CONCRETE, CNP-1CHIPSEAL, CHP-1CONCRETE PAVING, CNC-3TREESSEE LANDSCAPE DRAWINGSEXISTING TREES TO REMAIN, PROTECT IN PLACESEE LANDSCAPE DRAWINGSXXXXREQUIRED SETBACKSTRUNCATED DOMES, TD-1SPORTS COATING ON EXISTING CONCRETEIRRIGATED GARDENSEE LANDSCAPE DWGSSEE A7.31 MATERIAL AND EQUIPMENT SCHEDULE FOR MORE INFORMATION ABOUT MATERIAL DESIGNATIONSLIMIT OF WORKRIVERSIDE COBBLE, RVC-1ASPHALT, SLURRY COATED, ASP-1FNC 2: CHAIN LINK FENCING/GATES; 12' HFNC 3: AMERISTAR AEGIS GENESIS, SINGLE TOP RAIL, 6' HFNC 4: 4" x 1/4" BAR STOCK FENCE PICKETS; 1/2" DIA. CROSS BAR @ 3' h; TOTAL FENCE HEIGHT 4'; BASE PLATE ANCHORED TO CURBXXX'NATIVE FESCUE', SEE LANDSCAPE DWGSBIMLADERA LINDA COMMUNITY PARK PROJECT:CITY OF RANCHO PALOS VERDES:A r c h i t e c t u r e a n d U r b a n D e s i g n5898 Blackwelder Street, Ground FloorCulver City, CA 90232(Tel) 310-559-5720 (Fax) 310-559-8220ARCHITECTCONSULTANTS.ARCHITECT'S / ENGINEER'S STAMPThe drawings and specifications, ideas, designs, and arrangements are and shallremain the property of the architect. No part thereof shall be copied or used inconnection with any work or project other than the specific project for which theyhave been prepared without the written consent of the architect. Visual contactwith these drawings or specifications shall constitute evidence of acceptance ofthese restrictions.Written dimensions on these drawings shall have precedence over scaleddimensions. Contractor shall verify and be responsible for all dimensions andconditions on the job and this office must be notified of any variation from thedimensions and conditions shown by these drawings. Shop details must besubmitted to this office for approval before proceeding with fabrication.© MDA Johnson Favaro 2017CHECKED BY:No.IssueDRAWN BY:DateTITLE:SHEET:PROJECT #:SCALE:DATE:CITY APPROVALSPROJECT32201 Forrestal DriveRancho Palos Verdes, CA 9027530940 Hawthorne Blvd.Rancho Palos Verdes, CA 902752/24/23SIGNED 12/30/213/7/2023 2:19:09 PMA1.02BSITE PLAN -PERIMETER FENCINGREF.SCALE:A1.02BA1.031" = 40'-0"SITE PLAN -PERIMETER FENCING1ISSUES/REVISIONS21A ASI 21 12.27.2229A ASI 29 03.06.2329A29A7DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 7272* * ** * *487272* * ** * *484032241684032241684.1LIMIT OF WORKLIMIT OF WORK7' - 5" 106' - 0" 46' - 2" 36' - 10"8' - 10"2' - 3"6' - 1"6' - 8"173' - 11"5' - 11"158' - 7"5' - 9" 15' - 9" 8' - 3" 90' - 5"15' - 0" 46' - 3" 8' - 1" 42' - 6"15' - 10" 6' - 6" 105' - 4"87' - 5"93' - 1"91' - 11"116' - 0 3/4" 9' - 4" 32' - 2 1/2"158' - 7"A1.07F1TYPFENCEA1.07F3TYP2' - 0"3' - 6"2' - 0"7' - 6"2 ' - 0 "3 ' - 6 "4 ' - 0 "9 ' - 6 "2' - 0"3' - 6"4' - 0"9' - 6"XXXXXXXXXXXXXXX29ALEGENDPARTIALLY PLANTED ZONE, REFERENCE A1.07FWIRE CABLE FENCESTORM DRAIN PER CIVILCLEAR PATH ZONE, REFERENCE A1.07FBIOSWALESEE CIVIL AND LANDSCAPE DWGSIRRIGATED GRASS LAWNSEE LANDSCAPE DWGSDECOMPOSED GRANITE, DG-1, REFER TO 8/LP2.0LEGENDPROPERTY LINECOASTAL SAGE SCRUB, SEE LANDSCAPE DWGSGRAVEL, GR-1, REFER TO 8/LP2.0EXISTING FENCE TO REMAINFNC 1: CHAINLINK FENCING/GATES; 6 'HCOASTAL NATIVE WILDFLOWERS, SEE LANDSCAPE DWGSCOMPACTED DIRTENGINEERED WOOD FIBRE PLAY SURFACING, EWF-1BASKETBALL SPORTS COATING ON CONCRETE, SPC-1PERVIOUS CONCRETE, CNP-1CHIPSEAL, CHP-1CONCRETE PAVING, CNC-3TREESSEE LANDSCAPE DRAWINGSEXISTING TREES TO REMAIN, PROTECT IN PLACESEE LANDSCAPE DRAWINGSXXXXREQUIRED SETBACKSTRUNCATED DOMES, TD-1SPORTS COATING ON EXISTING CONCRETEIRRIGATED GARDENSEE LANDSCAPE DWGSSEE A7.31 MATERIAL AND EQUIPMENT SCHEDULE FOR MORE INFORMATION ABOUT MATERIAL DESIGNATIONSLIMIT OF WORKRIVERSIDE COBBLE, RVC-1ASPHALT, SLURRY COATED, ASP-1FNC 2: CHAIN LINK FENCING/GATES; 12' HFNC 3: AMERISTAR AEGIS GENESIS, SINGLE TOP RAIL, 6' HFNC 4: 4" x 1/4" BAR STOCK FENCE PICKETS; 1/2" DIA. CROSS BAR @ 3' h; TOTAL FENCE HEIGHT 4'; BASE PLATE ANCHORED TO CURBXXX'NATIVE FESCUE', SEE LANDSCAPE DWGSBIMLADERA LINDA COMMUNITY PARK PROJECT:CITY OF RANCHO PALOS VERDES:A r c h i t e c t u r e a n d U r b a n D e s i g n5898 Blackwelder Street, Ground FloorCulver City, CA 90232(Tel) 310-559-5720 (Fax) 310-559-8220ARCHITECTCONSULTANTS.ARCHITECT'S / ENGINEER'S STAMPThe drawings and specifications, ideas, designs, and arrangements are and shallremain the property of the architect. No part thereof shall be copied or used inconnection with any work or project other than the specific project for which theyhave been prepared without the written consent of the architect. Visual contactwith these drawings or specifications shall constitute evidence of acceptance ofthese restrictions.Written dimensions on these drawings shall have precedence over scaleddimensions. Contractor shall verify and be responsible for all dimensions andconditions on the job and this office must be notified of any variation from thedimensions and conditions shown by these drawings. Shop details must besubmitted to this office for approval before proceeding with fabrication.© MDA Johnson Favaro 2017CHECKED BY:No.IssueDRAWN BY:DateTITLE:SHEET:PROJECT #:SCALE:DATE:CITY APPROVALSPROJECT32201 Forrestal DriveRancho Palos Verdes, CA 9027530940 Hawthorne Blvd.Rancho Palos Verdes, CA 902752/24/23SIGNED 12/30/213/7/2023 2:21:45 PMA1.05BHIGH TIER PERIMETERFENCING DIMENSIONPLANREF.SCALE:A1.05BA1.02B1" = 20'-0"HIGH TIER PERIMETER FENCING DIMENSION PLAN1NNmag. north29AISSUES/REVISIONS29A ASI 29 03.06.2329A7DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 UPUPM.1LKJHGFEDC4.131.1B2M14AA.1B.1L.22.13.111 12 131098765432115 1716 1918 2120 2322 2524 2726 2840 39 385251535441STDSTDSTD STD STD STD STD STD STD STDxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxx144355LIMIT OF WORKLIMIT OF WORKFRONT AND STREET SIDE SET BACKREAR SETBACKxxxxxxxxxxxxxxxxxx5' - 0"6' - 4"48' - 11" 6' - 0"30' - 4" 5' - 5" 20' - 4"59' - 7" 5' - 11"8' - 5"9' - 8"3' - 2"12' - 5" 3' - 5" 71' - 9"32' - 9" 9' - 8" 21' - 6"28' - 4"27' - 2"22' - 0"21' - 0"5' - 9" 114' - 6"8' - 3" 90' - 5"17' - 10" 74' - 1"87' - 5"4' - 11"8' - 4" 30' - 9" 14' - 2"4' - 2"59' - 10"57' - 7"34' - 4"8' - 0"5' - 9"58' - 11"91' - 4"A1.07F1TYPA1.07F2TYPFENCE29AA1.07F3TYP2 ' - 0 "3 ' - 6 "2 ' - 0 "7 ' - 6 "5' - 0"5' - 0"10' - 0"2' - 0"3' - 6"4' - 0"9' - 6"2' - 0"3' - 6"4' - 0"9' - 6"XXXXXXXXXXXXXXXXXXXXXXXXXX29ALEGENDPARTIALLY PLANTED ZONE, REFERENCE A1.07FWIRE CABLE FENCESTORM DRAIN PER CIVILCLEAR PATH ZONE, REFERENCE A1.07FBIOSWALESEE CIVIL AND LANDSCAPE DWGSIRRIGATED GRASS LAWNSEE LANDSCAPE DWGSDECOMPOSED GRANITE, DG-1, REFER TO 8/LP2.0LEGENDPROPERTY LINECOASTAL SAGE SCRUB, SEE LANDSCAPE DWGSGRAVEL, GR-1, REFER TO 8/LP2.0EXISTING FENCE TO REMAINFNC 1: CHAINLINK FENCING/GATES; 6 'HCOASTAL NATIVE WILDFLOWERS, SEE LANDSCAPE DWGSCOMPACTED DIRTENGINEERED WOOD FIBRE PLAY SURFACING, EWF-1BASKETBALL SPORTS COATING ON CONCRETE, SPC-1PERVIOUS CONCRETE, CNP-1CHIPSEAL, CHP-1CONCRETE PAVING, CNC-3TREESSEE LANDSCAPE DRAWINGSEXISTING TREES TO REMAIN, PROTECT IN PLACESEE LANDSCAPE DRAWINGSXXXXREQUIRED SETBACKSTRUNCATED DOMES, TD-1SPORTS COATING ON EXISTING CONCRETEIRRIGATED GARDENSEE LANDSCAPE DWGSSEE A7.31 MATERIAL AND EQUIPMENT SCHEDULE FOR MORE INFORMATION ABOUT MATERIAL DESIGNATIONSLIMIT OF WORKRIVERSIDE COBBLE, RVC-1ASPHALT, SLURRY COATED, ASP-1FNC 2: CHAIN LINK FENCING/GATES; 12' HFNC 3: AMERISTAR AEGIS GENESIS, SINGLE TOP RAIL, 6' HFNC 4: 4" x 1/4" BAR STOCK FENCE PICKETS; 1/2" DIA. CROSS BAR @ 3' h; TOTAL FENCE HEIGHT 4'; BASE PLATE ANCHORED TO CURBXXX'NATIVE FESCUE', SEE LANDSCAPE DWGSBIMLADERA LINDA COMMUNITY PARK PROJECT:CITY OF RANCHO PALOS VERDES:A r c h i t e c t u r e a n d U r b a n D e s i g n5898 Blackwelder Street, Ground FloorCulver City, CA 90232(Tel) 310-559-5720 (Fax) 310-559-8220ARCHITECTCONSULTANTS.ARCHITECT'S / ENGINEER'S STAMPThe drawings and specifications, ideas, designs, and arrangements are and shallremain the property of the architect. No part thereof shall be copied or used inconnection with any work or project other than the specific project for which theyhave been prepared without the written consent of the architect. Visual contactwith these drawings or specifications shall constitute evidence of acceptance ofthese restrictions.Written dimensions on these drawings shall have precedence over scaleddimensions. Contractor shall verify and be responsible for all dimensions andconditions on the job and this office must be notified of any variation from thedimensions and conditions shown by these drawings. Shop details must besubmitted to this office for approval before proceeding with fabrication.© MDA Johnson Favaro 2017CHECKED BY:No.IssueDRAWN BY:DateTITLE:SHEET:PROJECT #:SCALE:DATE:CITY APPROVALSPROJECT32201 Forrestal DriveRancho Palos Verdes, CA 9027530940 Hawthorne Blvd.Rancho Palos Verdes, CA 902752/24/23SIGNED 12/30/213/7/2023 2:22:50 PMA1.06BMID TIER PERIMETERFENCING DIMENSIONPLANNNmag. northREF.SCALE:A1.06BA1.02B1" = 20'-0"MID TIER PERIMETER FENCING DIMENSION PLAN129AISSUES/REVISIONS14A ASI 14 7.12.2221A ASI 21 12.27.2229A ASI 29 03.06.2329A7DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 M.14.1LIMIT OF WORK16' - 1"3' - 5"40' - 7" 9' - 8" 21' - 6"4' - 5"48' - 11" 6' - 0"59' - 7" 5' - 11"58' - 11"56' - 1"91' - 4"402' - 8"6' - 3"A1.07C230' - 4"xxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxx3' - 2" 87' - 8"29A4 ' - 0 "4 ' - 0 "PARTIALLY PLANTED ZONE8 ' - 0 "PARTIALLY PLANTED ZONE2' - 0"3' - 6"2' - 0"7' - 6"2' - 0"3' - 6"4' - 0"9' - 6"5' - 0"5' - 0"10' - 0"XXXXXXXXXXXXXXXXXXXXXXXXXXXXXFENCELEGENDPARTIALLY PLANTED ZONE, REFERENCE A1.07FWIRE CABLE FENCESTORM DRAIN PER CIVILCLEAR PATH ZONE, REFERENCE A1.07FBIOSWALESEE CIVIL AND LANDSCAPE DWGSIRRIGATED GRASS LAWNSEE LANDSCAPE DWGSDECOMPOSED GRANITE, DG-1, REFER TO 8/LP2.0LEGENDPROPERTY LINECOASTAL SAGE SCRUB, SEE LANDSCAPE DWGSGRAVEL, GR-1, REFER TO 8/LP2.0EXISTING FENCE TO REMAINFNC 1: CHAINLINK FENCING/GATES; 6 'HCOASTAL NATIVE WILDFLOWERS, SEE LANDSCAPE DWGSCOMPACTED DIRTENGINEERED WOOD FIBRE PLAY SURFACING, EWF-1BASKETBALL SPORTS COATING ON CONCRETE, SPC-1PERVIOUS CONCRETE, CNP-1CHIPSEAL, CHP-1CONCRETE PAVING, CNC-3TREESSEE LANDSCAPE DRAWINGSEXISTING TREES TO REMAIN, PROTECT IN PLACESEE LANDSCAPE DRAWINGSXXXXREQUIRED SETBACKSTRUNCATED DOMES, TD-1SPORTS COATING ON EXISTING CONCRETEIRRIGATED GARDENSEE LANDSCAPE DWGSSEE A7.31 MATERIAL AND EQUIPMENT SCHEDULE FOR MORE INFORMATION ABOUT MATERIAL DESIGNATIONSLIMIT OF WORKRIVERSIDE COBBLE, RVC-1ASPHALT, SLURRY COATED, ASP-1FNC 2: CHAIN LINK FENCING/GATES; 12' HFNC 3: AMERISTAR AEGIS GENESIS, SINGLE TOP RAIL, 6' HFNC 4: 4" x 1/4" BAR STOCK FENCE PICKETS; 1/2" DIA. CROSS BAR @ 3' h; TOTAL FENCE HEIGHT 4'; BASE PLATE ANCHORED TO CURBXXX'NATIVE FESCUE', SEE LANDSCAPE DWGSBIMLADERA LINDA COMMUNITY PARK PROJECT:CITY OF RANCHO PALOS VERDES:A r c h i t e c t u r e a n d U r b a n D e s i g n5898 Blackwelder Street, Ground FloorCulver City, CA 90232(Tel) 310-559-5720 (Fax) 310-559-8220ARCHITECTCONSULTANTS.ARCHITECT'S / ENGINEER'S STAMPThe drawings and specifications, ideas, designs, and arrangements are and shallremain the property of the architect. No part thereof shall be copied or used inconnection with any work or project other than the specific project for which theyhave been prepared without the written consent of the architect. Visual contactwith these drawings or specifications shall constitute evidence of acceptance ofthese restrictions.Written dimensions on these drawings shall have precedence over scaleddimensions. Contractor shall verify and be responsible for all dimensions andconditions on the job and this office must be notified of any variation from thedimensions and conditions shown by these drawings. Shop details must besubmitted to this office for approval before proceeding with fabrication.© MDA Johnson Favaro 2017CHECKED BY:No.IssueDRAWN BY:DateTITLE:SHEET:PROJECT #:SCALE:DATE:CITY APPROVALSPROJECT32201 Forrestal DriveRancho Palos Verdes, CA 9027530940 Hawthorne Blvd.Rancho Palos Verdes, CA 902752/24/23SIGNED 12/30/213/7/2023 2:23:42 PMA1.07BLOW TIER PERIMETERFENCING DIMENSIONPLANNNmag. northREF.SCALE:A1.07BA1.021" = 20'-0"LOW TIER SITE PLAN129AISSUES/REVISIONS29A ASI 29 03.06.2329A7DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 UPM.1LK4.1ML.260' - 6" 27' - 2"28' - 4"5' - 0"6' - 4"48' - 11" 6' - 0"59' - 7" 5' - 11"35' - 9" 20' - 4" 2' - 10"30' - 4"91' - 4"15' - 8"3' - 5" 7' - 10" 32' - 9" 9' - 8" 21' - 6"29AXXXXXXXXSEE 1/A1.07B 6' - 3"29ALEGENDPARTIALLY PLANTED ZONE, REFERENCE A1.07FWIRE CABLE FENCESTORM DRAIN PER CIVILCLEAR PATH ZONE, REFERENCE A1.07FBIOSWALESEE CIVIL AND LANDSCAPE DWGSIRRIGATED GRASS LAWNSEE LANDSCAPE DWGSDECOMPOSED GRANITE, DG-1, REFER TO 8/LP2.0LEGENDPROPERTY LINECOASTAL SAGE SCRUB, SEE LANDSCAPE DWGSGRAVEL, GR-1, REFER TO 8/LP2.0EXISTING FENCE TO REMAINFNC 1: CHAINLINK FENCING/GATES; 6 'HCOASTAL NATIVE WILDFLOWERS, SEE LANDSCAPE DWGSCOMPACTED DIRTENGINEERED WOOD FIBRE PLAY SURFACING, EWF-1BASKETBALL SPORTS COATING ON CONCRETE, SPC-1PERVIOUS CONCRETE, CNP-1CHIPSEAL, CHP-1CONCRETE PAVING, CNC-3TREESSEE LANDSCAPE DRAWINGSEXISTING TREES TO REMAIN, PROTECT IN PLACESEE LANDSCAPE DRAWINGSXXXXREQUIRED SETBACKSTRUNCATED DOMES, TD-1SPORTS COATING ON EXISTING CONCRETEIRRIGATED GARDENSEE LANDSCAPE DWGSSEE A7.31 MATERIAL AND EQUIPMENT SCHEDULE FOR MORE INFORMATION ABOUT MATERIAL DESIGNATIONSLIMIT OF WORKRIVERSIDE COBBLE, RVC-1ASPHALT, SLURRY COATED, ASP-1FNC 2: CHAIN LINK FENCING/GATES; 12' HFNC 3: AMERISTAR AEGIS GENESIS, SINGLE TOP RAIL, 6' HFNC 4: 4" x 1/4" BAR STOCK FENCE PICKETS; 1/2" DIA. CROSS BAR @ 3' h; TOTAL FENCE HEIGHT 4'; BASE PLATE ANCHORED TO CURBXXX'NATIVE FESCUE', SEE LANDSCAPE DWGSBIMLADERA LINDA COMMUNITY PARK PROJECT:CITY OF RANCHO PALOS VERDES:A r c h i t e c t u r e a n d U r b a n D e s i g n5898 Blackwelder Street, Ground FloorCulver City, CA 90232(Tel) 310-559-5720 (Fax) 310-559-8220ARCHITECTCONSULTANTS.ARCHITECT'S / ENGINEER'S STAMPThe drawings and specifications, ideas, designs, and arrangements are and shallremain the property of the architect. No part thereof shall be copied or used inconnection with any work or project other than the specific project for which theyhave been prepared without the written consent of the architect. Visual contactwith these drawings or specifications shall constitute evidence of acceptance ofthese restrictions.Written dimensions on these drawings shall have precedence over scaleddimensions. Contractor shall verify and be responsible for all dimensions andconditions on the job and this office must be notified of any variation from thedimensions and conditions shown by these drawings. Shop details must besubmitted to this office for approval before proceeding with fabrication.© MDA Johnson Favaro 2017CHECKED BY:No.IssueDRAWN BY:DateTITLE:SHEET:PROJECT #:SCALE:DATE:CITY APPROVALSPROJECT32201 Forrestal DriveRancho Palos Verdes, CA 9027530940 Hawthorne Blvd.Rancho Palos Verdes, CA 902752/24/23SIGNED 12/30/213/7/2023 2:24:15 PMA1.07CPERIMETER FENCINGENLARGED PLANSREF.SCALE:A1.07CA1.02B1" = 10'-0"MID TIER TO LOW TIER PERIMETER FENCING DIMENSION PLAN1REF.SCALE:A1.07CA1.07B1" = 10'-0"LOW TIER PERIMETER FENCING TO EXISITING FENCE229AREF.SCALE:A1.07CEXISITING FENCE TO NEW FENCE3ISSUES/REVISIONS29A ASI 29 03.06.2329A7DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 3' - 6"3' - 0"2' - 0" 3' - 6"25% PLANTED AREA4' - 0"CONCRETE FOOTINGTRACTOR FENCE CO. 5" X 6.5' TREATED WOOD FENCE POST. CONTRACTOR TO DRILL 1/2" DIAMETER HOLES FOR STAINLESS STEEL CABLEAREA OF CLEAR PATH25% PLANTED AREA100% PLANTED AREA100% PLANTED AREAHAAS STAINLESS 1/4" X 500' TYPE 316 STAINLESS STEEL CABLE, TYP.2"DIA1' - 0"TYP. 6' - 0" TYP.6 3/4"TRACTOR FENCE CO. 5" X 6.5' TREATED WOOD FENCE POST, TYP.HAAS STAINLESS 1/4" X 500' TYPE 316 STAINLESS STEEL CABLE,TYP. DO NOT INSTALL IN TENSION4A1.07F100% PLANTED AREA100% PLANTED AREA2' - 0"3' - 6"25% PLANTED AREA4' - 0"AREA OF CLEAR PATH25% PLANTED AREA50' - 0"FENCEPLANTING PERFORTHCOMINGLANDSCAPE ASI3' - 6"3' - 0"25% PLANTED AREA5' - 0"AREA OF CLEAR PATH5' - 0"CONCRETE FOOTINGEDGING PER LANDSCAPETRACTOR FENCE CO. 5" X 6.5' TREATED WOOD FENCE POST. CONTRACTOR TO DRILL 1/2" DIAMETER HOLES FOR STAINLESS STEEL CABLE100% PLANTED AREAGRASSHAAS STAINLESS 1/4" X 500' TYPE 316 STAINLESS STEEL CABLE, TYP.2"DIA1' - 0"5A1.07F100% PLANTED AREAGRASS25% PLANTED AREA5' - 0"AREA OF CLEAR PATH5' - 0"50' - 0"FENCEPLANTING PER FORTHCOMINGLANDSCAPE ASI .375" AT END POST .531" .646" 1" STAINLESS STEEL FLAT WASHER PER MANUFACTURERHAAS STAINLESS 1/4" DIAMETER TYPE 316 STAINLESS STEEL CABLEULTRA-TEC INVISIWARE RADIUS FERRULE (RF-8)100% PLANTED AREA100% PLANTED AREA2' - 0"3' - 6"2' - 0"AREA OF CLEAR PATH25% PLANTED AREA50' - 0"25% PLANTED AREAPLANTING PER FORTHCOMING LANDSCAPE ASIBIMLADERA LINDA COMMUNITY PARK PROJECT:CITY OF RANCHO PALOS VERDES:A r c h i t e c t u r e a n d U r b a n D e s i g n5898 Blackwelder Street, Ground FloorCulver City, CA 90232(Tel) 310-559-5720 (Fax) 310-559-8220ARCHITECTCONSULTANTS.ARCHITECT'S / ENGINEER'S STAMPThe drawings and specifications, ideas, designs, and arrangements are and shallremain the property of the architect. No part thereof shall be copied or used inconnection with any work or project other than the specific project for which theyhave been prepared without the written consent of the architect. Visual contactwith these drawings or specifications shall constitute evidence of acceptance ofthese restrictions.Written dimensions on these drawings shall have precedence over scaleddimensions. Contractor shall verify and be responsible for all dimensions andconditions on the job and this office must be notified of any variation from thedimensions and conditions shown by these drawings. Shop details must besubmitted to this office for approval before proceeding with fabrication.© MDA Johnson Favaro 2017CHECKED BY:No.IssueDRAWN BY:DateTITLE:SHEET:PROJECT #:SCALE:DATE:CITY APPROVALSPROJECT32201 Forrestal DriveRancho Palos Verdes, CA 9027530940 Hawthorne Blvd.Rancho Palos Verdes, CA 902752/24/23SIGNED 12/30/213/7/2023 2:24:57 PMA1.07FPERIMETER FENCINGPLANS AND DETAILSREF.SCALE:A1.07FA1.023/8" = 1'-0"TYP. NON-TURF PLANTING ON TWO SIDES4REF.SCALE:A1.07FGXX3/4" = 1'-0"TYP. FENCING ELEVATION6REF.SCALE:A1.07FA1.05B3/8" = 1'-0"TYP. NON-TURF PLANTING ON TWO SIDES WITH FENCE1REF.SCALE:A1.07FA1.07F3/8" = 1'-0"TYP. NON-TURF PLANTING ON ONE SIDE5REF.SCALE:A1.07FA1.06B3/8" = 1'-0"TYP. NON-TURF PLANTING ON ONE SIDE2ISSUES/REVISIONS29A ASI 29 03.06.2329AREF.SCALE:A1.07F12" = 1'-0"CABLE TERMINATION AT END POST7REF.SCALE:A1.07FA1.05B3/8" = 1'-0"TYP. NON-TURF PLANTING ON TWO SIDES37DocuSign Envelope ID: B2FB1F9B-69C2-4668-B551-F27C5F205D11 Certificate Of Completion Envelope Id: B2FB1F9B69C24668B551F27C5F205D11 Status: Completed Subject: Complete with DocuSign: 8405 Ladera Linda CCO 26_rev1.pdf, 8405 Ladera Linda CCO 27.pdf Source Envelope: Document Pages: 31 Signatures: 6 Envelope Originator: Certificate Pages: 5 Initials: 2 James O'Neill AutoNav: Enabled EnvelopeId Stamping: Enabled Time Zone: (UTC-08:00) Pacific Time (US & Canada) 30940 Hawthorne Blvd. Rancho Palos Verdes, CA 90275 joneill@rpvca.gov IP Address: 72.34.97.146 Record Tracking Status: Original 5/9/2023 9:33:25 AM Holder: James O'Neill joneill@rpvca.gov Location: DocuSign Signer Events Signature Timestamp Ramzi Awwad rawwad@rpvca.gov Security Level: Email, Account Authentication (None) Signature Adoption: Drawn on Device Using IP Address: 72.34.97.146 Sent: 5/9/2023 9:38:14 AM Viewed: 5/10/2023 8:15:45 AM Signed: 5/10/2023 8:20:30 AM Electronic Record and Signature Disclosure: Accepted: 3/2/2023 10:45:19 AM ID: 3242b72d-4755-489d-8e5f-7c62dc360470 Trang Nguyen tnguyen@rpvca.gov Director of Finance City of Rancho Palos Verdes Security Level: Email, Account Authentication (None) Signature Adoption: Pre-selected Style Using IP Address: 72.34.97.146 Sent: 5/10/2023 8:20:41 AM Viewed: 5/11/2023 9:20:08 AM Signed: 5/11/2023 9:24:49 AM Electronic Record and Signature Disclosure: Not Offered via DocuSign Ara Mihranian aram@rpvca.gov Security Level: Email, Account Authentication (None) Signature Adoption: Uploaded Signature Image Using IP Address: 104.34.113.36 Sent: 5/11/2023 9:25:03 AM Viewed: 5/11/2023 9:46:14 AM Signed: 5/11/2023 9:47:31 AM Electronic Record and Signature Disclosure: Accepted: 5/11/2023 9:46:14 AM ID: b408e580-a091-48b6-86fd-1d58b84ebb90 In Person Signer Events Signature Timestamp Editor Delivery Events Status Timestamp Agent Delivery Events Status Timestamp Intermediary Delivery Events Status Timestamp Certified Delivery Events Status Timestamp Carbon Copy Events Status Timestamp Erin Jones ejones@griffinstructures.com Security Level: Email, Account Authentication (None) Sent: 5/11/2023 9:47:44 AM Electronic Record and Signature Disclosure: Not Offered via DocuSign Lorna Cloke lornac@rpvca.gov Security Level: Email, Account Authentication (None) Sent: 5/11/2023 9:47:44 AM Electronic Record and Signature Disclosure: Not Offered via DocuSign Lincoln Lo llo@rpvca.gov Public Works Deputy Director City of Rancho Palos Verdes Security Level: Email, Account Authentication (None) Sent: 5/11/2023 9:47:45 AM Electronic Record and Signature Disclosure: Not Offered via DocuSign City Clerk cityclerk@rpvca.gov Security Level: Email, Account Authentication (None) Sent: 5/11/2023 9:47:46 AM Viewed: 5/11/2023 10:03:25 AM Electronic Record and Signature Disclosure: Accepted: 2/1/2023 3:10:58 PM ID: 505eed45-7ed0-4db8-aae6-ef6eedfef03d Witness Events Signature Timestamp Notary Events Signature Timestamp Envelope Summary Events Status Timestamps Envelope Sent Hashed/Encrypted 5/9/2023 9:38:14 AM Certified Delivered Security Checked 5/11/2023 9:46:14 AM Signing Complete Security Checked 5/11/2023 9:47:31 AM Completed Security Checked 5/11/2023 9:47:46 AM Payment Events Status Timestamps Electronic Record and Signature Disclosure ELECTRONIC RECORD AND SIGNATURE DISCLOSURE From time to time, City of Rancho Palos Verdes (we, us or Company) may be required by law to provide to you certain written notices or disclosures. Described below are the terms and conditions for providing to you such notices and disclosures electronicall y through the DocuSign system. Please read the information below carefully and thoroughly, and if you can access this information electronically to your satisfaction and agree to this Electronic Record and Signature Disclosure (ERSD), please confirm your agreement by selecting the check-box next to ‘I agree to use electronic records and signatures’ before clicking ‘CONTINUE’ within the DocuSign system. Getting paper copies At any time, you may request from us a paper copy of any record provided or made av ailable electronically to you by us. You will have the ability to download and print documents we send to you through the DocuSign system during and immediately after the signing session and, if you elect to create a DocuSign account, you may access the documents for a limited period of time (usually 30 days) after such documents are first sent to you. After such time, if you wish for us to send you paper copies of any such documents from our office to you, you will be charged a $0.00 per-page fee. You may request delivery of such paper copies from us by following the procedure described below. Withdrawing your consent If you decide to receive notices and disclosures from us electronically, you may at any time change your mind and tell us that thereafter you want to receive required notices and disclosures only in paper format. How you must inform us of your decision to receive future notices and disclosure in paper format and withdraw your consent to receive notices and disclosures electronically is described below. Consequences of changing your mind If you elect to receive required notices and disclosures only in paper format, it will slow the speed at which we can complete certain steps in transactions with you and delivering services to you because we will need first to send the required notices or disclosures to you in paper format, and then wait until we receive back from you your acknowledgment of your receipt of such paper notices or disclosures. Further, you will no longer be able to use the DocuSign system to receive required notices and consents electronically from us or to sign electronically documents from us. All notices and disclosures will be sent to you electronically Electronic Record and Signature Disclosure created on: 6/15/2021 5:55:39 PM Parties agreed to: Ramzi Awwad, Ara Mihranian, City Clerk Unless you tell us otherwise in accordance with the procedures described herein, we will provide electronically to you through the DocuSign system all required notices, disclosures, authorizations, acknowledgements, and other documents that are required to be provided or made available to you during the course of our relationship with you. To reduce the chance of you inadvertently not receiving any notice or disclosure, we prefer to provide all of the required notices and disclosures to you by the same method and to the same address that you have given us. Thus, you can receive all the disclosures and notices electronically or in paper format through the paper mail delivery system. If you do not agree with this process, please let us know as described below. Please also see the paragraph immediately above that describes the consequences of your electing not to receive delivery of the notices and disclosures electronically from us. How to contact City of Rancho Palos Verdes: You may contact us to let us know of your changes as to how we may contact you electronically, to request paper copies of certain information from us, and to withdraw your prior consent to receive notices and disclosures electronically as follows: To contact us by email send messages to: terit@rpvca.gov To advise City of Rancho Palos Verdes of your new email address To let us know of a change in your email address where we should send notices and disclosures electronically to you, you must send an email message to us at terit@rpvca.gov and in the body of such request you must state: your previous email address, your new email address. We do not require any other information from you to change your email address. If you created a DocuSign account, you may update it with your new email address through your account preferences. To request paper copies from City of Rancho Palos Verdes To request delivery from us of paper copies of the notices and disclosures previously provided by us to you electronically, you must send us an email to terit@rpvca.gov and in the body of such request you must state your email address, full name, mailing address, and telephone number. We will bill you for any fees at that time, if any. To withdraw your consent with City of Rancho Palos Verdes To inform us that you no longer wish to receive future notices and disclosures in electronic format you may: i. decline to sign a document from within your signing session, and on the subsequent page, select the check-box indicating you wish to withdraw your consent, or you may; ii. send us an email to terit@rpvca.gov and in the body of such request you must state your email, full name, mailing address, and telephone number. We do not need any other information from you to withdraw consent.. The consequences of your withdrawing consent for online documents will be that transactions may take a longer time to process.. Required hardware and software The minimum system requirements for using the DocuSign system may change over time. The current system requirements are found here: https://support.docusign.com/guides/signer-guide- signing-system-requirements. Acknowledging your access and consent to receive and sign documents electronically To confirm to us that you can access this information electronically, which will be similar to other electronic notices and disclosures that we will provide to you, please confirm that you have read this ERSD, and (i) that you are able to print on paper or electronically save this ERSD for your future reference and access; or (ii) that you are able to email this ERSD to an email address where you will be able to print on paper or save it for your future reference and access. Further, if you consent to receiving notices and disclosures exclusively in electronic format as described herein, then select the check-box next to ‘I agree to use electronic records and signatures’ before clicking ‘CONTINUE’ within the DocuSign system. By selecting the check-box next to ‘I agree to use electronic records and signatures’, you confirm that:  You can access and read this Electronic Record and Signature Disclosure; and  You can print on paper this Electronic Record and Signature Disclosure, or save or send this Electronic Record and Disclosure to a location where you can print it, for future reference and access; and  Until or unless you notify City of Rancho Palos Verdes as described above, you consent to receive exclusively through electronic means all notices, disclosures, authorizations, acknowledgements, and other documents that are required to be provided or made available to you by City of Rancho Palos Verdes during the course of your relationship with City of Rancho Palos Verdes.